B130022 COVER SHEET

B130022 COVER SHEET
REQUEST FOR PROPOSAL #B130022
RETURN BID PROPOSAL TO:
THE RICHARD STOCKTON COLLEGE OF NEW JERSEY
101 VERA KING FARRIS DRIVE, BLDG. 70
GALLOWAY, NJ 08205-9441
FOR:
PURCHASE AND INSTALLATION OF TV STUDIO
COMMUMICATION EQUIPMENT
TOTAL BID PRICE: $____________________
FEDERAL ID# 222832788
NJ TAX EXEMPT AS PER NJSA 54:32b-1 ET SEQ.
HOURLY RATE FOR ADDITIONAL TRAINING:
$_________________________
1. BID PROPOSALS MUST BE RECEIVED AT OR BEFORE THE PUBLIC OPENING TIME OF 2:00 PM ON TUESDAY, MAY 28,
2013 AT THE FOLLOWING ADDRESS (NOTE: TELEPHONE, TELEFACSIMILE OR TELEGRAPH PROPOSALS WILL NOT BE
ACCEPTED):
PURCHASING DEPARTMENT
THE RICHARD STOCKTON COLLEGE OF NEW JERSEY
101 VERA KING FARRIS DRIVE, PLANT MGMT. BLDG. 70
GALLOWAY, NJ 08205-9441
2. THE BIDDER MUST SIGN THIS RFP COVER SHEET
3. THE BID PROPOSAL MUST INCLUDE ALL PRICE INFORMATION. PROPOSAL PRICES SHALL INCLUDE DELIVERY OF ALL
ITEMS, F.O.B. DESTINATION OR AS OTHERWISE PROVIDED. PRICE QUOTES MUST BE FIRM THROUGH ISSUANCE OF
CONTRACT.
4. ALL PROPOSAL PRICES MUST BE TYPED OR WRITTEN IN INK.
5. IN THE EVENT THAT THERE IS A DISCREPANCY BETWEEN THE UNIT PRICES AND THE EXTENDED TOTALS, THE UNIT
PRICES SHALL PREVAIL. IN THE EVENT THERE IS AN ERROR OF THE SUMMATION OF THE EXTENDED TOTALS, THE
COMPUTATION BY THE OWNER OF THE EXTENDED TOTALS SHALL GOVERN.
6. ALL CORRECTIONS, WHITE-OUTS, ERASURES, RESTRIKING OF TYPE, OR OTHER FORMS OF ALTERATION, OR THE
APPEARANCE OF ALTERATION, TO UNIT AND/OR TOTAL PRICES MUST BE INITIALED IN INK BY THE BIDDER.
7. THE BIDDER MUST COMPLETE AND SUBMIT WITH BID ALL REQUIRED BID DOCUMENTS (BID DOCUMENT CHECKLIST)
8. FOR SET ASIDE CONTRACTS ONLY, A BIDDER MUST BE REGISTERED WITH THE N.J. DEPARTMENT OF COMMERCE AS
A SMALL BUSINESS BY THE DATE OF BID OPENING.
9. BY SIGNING THIS RFP COVER SHEET, THE BIDDER CERTIFIES AND CONFIRMS THAT NEITHER THE BIDDER, ITS
REPRESENTATIVES, AGENTS OR LOBBYISTS HAVE INITIATED ANY INAPPROPRIATE CONTACT WITH ANY COLLEGE
EMPLOYEE DURING THE PROCUREMENT TO ATTEMPT TO AFFECT THE BIDDING PROCESS AND SHALL NOT DO SO
AFTER SUBMISSION OF THE BID PROPOSAL.
10. THE BIDDER MUST BE REGISTERED WITH THE DIVISION OF REVENUE AND MUST SUBMIT A BUSINESS
REGISTRATION CERTIFICATE WITH THE BID PROPOSAL.
11. PROPOSALS SHALL REMAIN OPEN FOR ACCEPTANCE AND MAY NOT BE CHANGED OR WITHDRAWN FOR A PERIOD
OF SIXTY (60) DAYS AFTER THE BID OPENING DATE.
TO BE COMPLETED BY BIDDER
12. FIRM NAME: ____________________________________________________________________________________
ADDRESS: _____________________________________________________________________________________
_____________________________________________________________________________________
13. BIDDER TEL#: __________________EXT: _______ 14. FEDERAL EMPLOYER IDENTIFICATION #:
_______________________________________________
15. BIDDER FAX# __________________
16. BIDDER E-MAIL ADDRESS: _________________________
SIGNATURE OF THE BIDDER ATTESTS THAT THE BIDDER HAS READ, UNDERSTANDS, AND AGREES TO ALL TERMS, CONDITIONS, AND
SPECIFICATIONS SET FORTH IN THE REQUEST FOR PROPOSAL INCLUDING ALL ADDENDA, FURTHERMORE, SIGNATURE BY THE BIDDER
SIGNIFIES THAT ADDENDA ISSUED, THE REQUEST FOR PROPOSAL, THE COLLEGE’S TERMS AND CONDITIONS (PAGE 2) AND THE
RESPONSIVE BID PROPOSAL CONSTITUTE A CONTRACT IMMEDIATELY UPON NOTICE OF ACCEPTANCE BY THE COLLEGE FOR ANY OR
ALL OF THE ITEMS BID, AND FOR THE LENGTH OF TIME INDICATED IN THE REQUEST FOR PROPOSAL. FAILURE TO ACCEPT THE
CONTRACT WITHIN THE TIME PERIOD INDICATED IN THE REQUEST FOR PROPOSAL, OR FAILURE TO HOLD PRICES OR TO MEET ANY
OTHER TERMS AND CONDITIONS AS DEFINED IN EITHER ADDENDA OR THE REQUEST FOR PROPOSAL DURING THE TERM OF THE
CONTRACT SHALL CONSTITUTE A BREACH AND MAY RESULT IN CONTRACT TERMINATION. A DEFAULTING CONTRACTOR MAY ALSO
BE LIABLE, AT THE OPTION OF THE COLLEGE, FOR THE DIFFERENCE BETWEEN THE CONTRACT PRICE AND THE PRICE BID BY AN
ALTERNATE VENDOR OF THE GOODS OR SERVICES IN ADDITION TO OTHER REMEDIES AVAILABLE.
ORIGINAL SIGNATURE OF BIDDER
DATE
PRINT/TYPE NAME
TITLE
1
THE RICHARD STOCKTON COLLEGE OF NEW JERSEY
TERMS AND CONDITIONS
The following terms and conditions apply to all contract or purchase agreements made with The Richard Stockton College of New Jersey unless specifically deleted on the College proposal form.
Vendors submitting offers to the College must cross out any paragraph they do not agree to meet. Any cross out or change to the College terms and conditions will be a factor in the determination of
an award of a contract or purchase agreement.
Bidders are notified by this statement that all terms and conditions will become part of any contract(s) or order(s) awarded as a request for proposal whether stated in part, in summary or by
reference. In the event a vendor’s terms and conditions conflict with the College, the College terms and conditions shall prevail.
1. STATE LAW REQUIRING MANDATORY COMPLIANCE BY ALL VENDORS
1.1 CORPORATE AUTHORITY – It is required that all corporations be authorized to do business in the
State of New Jersey. Corporations incorporated out of the State must file a Certificate of Authority with the
Secretary of State, Department of State, State House, Trenton, New Jersey 08625.Refer to N.J.S.A.Title
14A chapter 13-3.
1.2 ANTI-DISCRIMINATION – All parties to any contract with the College agree not to discriminate in
employment and agree to abide by all anti-discrimination laws including those contained within N.J.S.A.
10:2-1 through 10:2-4 N.J.S.A.10:5-31 through 10:5-38, and all rules and regulations issued thereunder.
1.3 PREVAILING WAGE ACT – The New Jersey Prevailing Wage Act P.L. 1986. Chapter 150, is hereby
made a part of every contract entered into on behalf of the College, except those contracts which are not
within the contemplation of the Act. The bidder’s signature on this proposal is his guarantee that neither he
nor any subcontractors he might employ to perform the work covered by this proposal are listed or are on
record in the Office of the Commissioner of the Department of Labor and Industry as one who has failed to
pay prevailing wages in accordance with the provisions of the Act.
1.4 THE WORKER AND COMMUNITY RIGHT TO KNOW ACT – (P.L. 1983, C. 315: N.J.S.A. 34:5A-1 et
seq.) required employers to label all containers of hazardous substances by March 1, 1985. By August 29,
1986, employers were to label all containers on College premises. Under the terms of the Act, the College is
considered an employer, therefore, all goods offered for purchase to the College must be labeled in
compliance with the provisions of the Act.
1.5 OWNERSHIP DISCLOSURE – Contracts for any work, goods or services cannot be issued to any firm
unless prior to or at the time of bid submission the firm has disclosed the names and addresses of all its
owner holding 10% or more of the firm’s stock or interest. Refer to N.J.P.L.1977 Chapter 33.
1.6 COMPLIANCE– STATE LAWS – It is agreed and understood that any contracts and/or orders placed
as a result of this proposal shall be governed and construed and the rights and obligations of the parties
hereto shall be determined in accordance with the laws of the STATE OF NEW JERSEY in New Jersey
courts without regard to principles of conflict of interest. This contract is subject to the New Jersey Tort
Claims Act, N.J.S.A. 59:1-1 et seq. and the New Jersey Contractual Liability Act, N.J.S.A. 59:13-1 et seq.
1.7 COMPLIANCE– LAWS - The vendor must comply with all local, state, and federal laws, rules and
regulations applicable to this contract and to the work to be done hereunder.
1.8 BUSINESS REGISTRATION – Compliance with the requirements of P.L. 2004, c. 57 et seq. (Business
Registration) and throughout the contract term. The firm understands that failure to abide by the
requirements of this statute and to continue to do so, constitutes a material breach of contract in the award
or performance of this contract such that the firm may be disqualified or payments pursuant to the contract
may be withheld until compliance is perfected. Further the firm agrees to advise in writing any
subcontractors of the need to comply with this requirement.
1.9 POLITICAL CONTRIBUTIONS DISCLOSURE –The firm will supply completed disclosure forms when
requested so it is compliant with the Requirements of Public Law 2005, Chapter 51(N.J.S.A.19:44A-20.1320.25) “Political Activity Disclosure”, dated September 22, 2004 and any statutes or regulations which result
thereof. The firm agrees during the course of this contract that it remains compliant with Public Law, Chapter
51and to notify the College if at any time it is no longer compliant. The firm understands that failure to abide
by the requirements of this statute and to continue to do so, constitutes a material breach of contract in the
award or performance of this contract such that the firm may be disqualified or payments made pursuant to
this contract may be withheld until the State Treasurer or his designee gives approval that the requirements
of the Public Law have been met.
2. LIABILITIES
2.1 LIABILITY–COPYRIGHT – The Contractor shall hold and save the College, its officers, agents,
servants and employees harmless from liability of any nature or kind for or on account of the use of any
copyrighted or uncopyrighted composition, secret process, patented or unpatented invention, article or
appliance furnished or used in the performance of this contract.
2.2 INDEMNIFICATION – The Contractor shall assume all risk of and responsibility for, and agrees to
indemnity, defend, and save harmless the College and its employees from and against any and all claims,
demands, suits, actions, recoveries, judgment, and costs and expenses in connection therewith on account
of the loss of life, property or injury or damage to the person, body or property of any person or persons
whatsoever, which shall arise from or result directly or indirectly from the work and/or materials supplied
under this contract. This indemnification obligation is not limited by, but is in addition to the insurance
obligations contained in this agreement. Additionally, the College reserves the right, including but not limited
to the engagement of a third party vendor, to manage, oversee and direct environmental remediation caused
or necessitated as a result of actions by Contractor, its employees, agents, assigns or subcontractors or
failures of their equipment.
2.3 INSURANCE – The successful bidder shall secure and maintain in force for the term of the contract
liability insurance is provided herein. The successful bidder shall provide the College with current certificates
of insurance for all coverages and renewals thereof which must contain the provision that the insurance
provided in the certificate shall not be cancelled for any reason except after thirty days written notice to the
College Purchasing Office. All such policies shall name The Richard Stockton College of New Jersey and
The State of New Jersey as “Additional Insured”.
The insurance to be provided by the successful bidder shall be as follows:
1. Comprehensive General Liability policy as broad as the standard coverage form currently in use in the
State of New Jersey, which shall not be circumscribed by any endorsements limiting the breadth of
coverage. The policy shall include an endorsement (broad form) for contractual liability and products liability
(completed operations). Limits of liability shall not be less than $1,000,000.00 per occurrence for bodily
injury liability and $1,000,000.00 per occurrence for property damage liability, but must be aggregated at
$3,000,000.00 or better. Policy shall be written to state that claims shall be covered as of the date of
occurrence rather than the date of claim. An acceptable alternative is a claims made policy having a
retroactive date the same as the last date of the last occurrence policy, and having an unlimited extended
reporting period. The insurance carriers shall have a Best’s Rating of “B+” or better.
2. Comprehensive General Automobile Liability policy covering owned, non-owned, and hired vehicles with
minimum limits of $1,000,000.00 combined single limits.
3. Worker’s Compensation insurance applicable to laws of the State of New Jersey and Employer’s Liability
insurance with a limit of not less than $1,000,000.00. Upon request, the vendor will provide certificates of such
insurance to the College Purchasing Office prior to the start of the Contract and periodically during the course of
a multi-year contract.
3. TERMS GOVERNING ALL PROPOSALS
3.1 PERFORMANCE GUARANTEE – The vendor hereby certifies; that The equipment offered is standard new
equipment and is the manufacturer’s latest model in production, with parts regularly used for the type of
equipment offered, that such parts are all in production and not likely to be discontinued; also, that no attachment
or part has been substituted or applied contrary to manufacturer’s recommendations and standard practice. All
equipment supplied to the College and operated by electrical current is UL approved. All new machines are to be
guaranteed for a period of one year from time of delivery and/or installation and prompt service rendered without
charge regardless of geographic location. Sufficient quantities of parts necessary for proper service to equipment
will be maintained at distribution points and service headquarters. Trained mechanics are regularly employed to
make necessary repairs to equipment in the territory from which the service request might emanate within a 48hour period or within the time accepted as industry practice. The vendor shall immediately replace any material
which is rejected for failure to meet the requirements of the College. All services rendered to the College shall be
performed in strict and full accordance with the specifications as agreed to in the contract. A service contract
shall not be considered complete until final approval by the College is rendered. Payment to vendors for services
rendered may not be made until final College approval is given.
3.2 DELIVERY GUARANTEES – Deliveries shall be made at such time and in such quantities as ordered in strict
accordance with conditions contained in proposal. The vendor shall be responsible for the delivery of material in
first class condition to the College or the purchaser under this contract, and in accordance with good commercial
practice.
3.3 MAINTENANCE OF RECORDS – The vendor shall maintain records for products and/or services delivered
against the contract for a period of three (3) years from the date of final payment. Such records shall be made
available to the College upon request.
3.4 TERMINATION – This order may be terminated by the Purchaser in whole or in part at anytime. Upon receipt
of a notice of termination, the Vendor shall stop all work in connection with this order, unless otherwise directed
by the Purchaser. The Vendor shall immediately take the necessary action to issue stop order to all subcontractors and/or suppliers in connection with any outstanding sub-contracts or orders for equipment, materials,
supplies, services and/or other charges for which the Vendor is committed and which relate directly to the
completion of this order. The Vendor shall furnish the Purchaser with a list of all such outstanding sub-contracts
and/or orders together with a report on their status. The Vendor shall be reimbursed for all reasonable expenses
incurred by reason of any termination of this Purchase Order (except for termination as a result of default by the
Vendor) including the Vendor's termination charges for which the Purchaser shall be liable. The final acceptance
of the Vendor's claim for expenses and termination charges shall be through negotiation and by agreement
between the Purchaser and the Vendor. In the event of such termination pursuant to a Notice of Termination
received by the Purchaser from the United States Government in connection with any Contract, Sub-Contract,
Grant or other form of agreement between the Purchaser and the Government, the Purchaser shall be obligated
hereunder to pay the Vendor only the amount which shall be determined to be, or approved as reimbursable to
the Purchase Order, the Government Contract, Sub-Contract, Grant or other form of agreement with respect to
this Purchase Order.
4. TERMS RELATING TO PRICE QUOTATION
4.1 PRICE FLUCTUATIONS DURING CONTRACT – All prices quoted shall be firm and not subject to increase
during the period of the contract. In the event of a manufacturer’s price decrease during the contract period, the
College shall receive the full benefit of such price reduction of any undelivered purchase order and on any
subsequent order placed during the contract period. The College must be notified in writing of any price reduction
within five (5) days of the effective date.
4.2 DELIVERY COSTS – Unless noted otherwise in the specifications, all prices for items in bid proposals are to
be submitted F.O.B. Destination. Proposals submitted other than F.O.B. Destination may not be considered.
Regardless of the method of quoting shipments, the vendors shall assume all liability and responsibility for the
delivery of merchandise in good condition to the College or designated purchaser. F.O.B. Destination does not
cover “spotting” but does include delivery on the receiving platforms of the College unless otherwise specified. No
additional charges will be allowed for any transportation costs resulting from partial shipments made at vendors
convenience when a single shipment is ordered. The weights and measures of the College receiving the
shipment shall govern.
4.3 TAX CHARGES – The College is exempt from NJ Sales, Use Tax and Local Taxes under N.J.S.A. 54:32B9(A). As a public, non-profit institution the College is exempt from Federal Excise Tax. These taxes must not be
included in vendor quotations or invoices.
4.4 PAYMENT TO VENDORS – Payment will be processed after the following information has been supplied and
receipt of goods or services verified:
After delivery of goods or services, vendor must submit a properly executed and/or signed invoice/billing to the
College Accounts Payable Department. All billings must show the College Purchase Order Number being
referenced. The B/L express receipt and/or packing slip and related papers must be sent to the consignee with
the merchandise. The College agrees to pay invoices within 30 days of the invoice date unless a discount is
given. All interest on late payments is subject to the New Jersey Prompt Payment Act N.J.S.A. 52:32-35.
5. CASH DISCOUNT
A discount period will commence on the date the properly executed and/or signed Vendor’s billing/invoice is
received by the College for goods or services that have been duly accepted by the College in accordance with
the terms, conditions, and specifications of the Contract/Purchase Order.
2
THE RICHARD STOCKTON COLLEGE OF NEW JERSEY
REQUEST FOR PROPOSAL
FOR
PURCHASE AND INSTALLATION OF
TV STUDIO COMMUNICATION EQUIPMENT
BID NO. B130022
RESPONSE DUE BY: Tuesday, May 28, 2013 @ 2:00 P.M.
3
PURPOSE AND INTENT
The Richard Stockton College of New Jersey (the “College”), a New Jersey public
college located in Pomona, New Jersey, is issuing a Request for Proposals (“RFP”)
to provide a turn-key project for the purchase, installation, integration, training and
maintenance of TV studio equipment for the College.
1.0
CONTRACT AND PROPOSAL INFORMATION
1.1
Issuing Office:
This Request for Proposal is issued by the Purchasing Office of the Richard
Stockton College of New Jersey, which shall be the sole point of contact for
purposes of the RFP and subsequent addendums, if applicable.
1.2
Proposal Preparation:
Respondents to this RFP shall follow the instructions contained in the
document in preparing and submitting a response proposal. Failure to abide
by the instructions may be deemed non-respondent to the RFP and may be
cause for rejection.
The primary medium for communication regarding this RFP shall be via the
internet (www.stockton.edu/purchasing). Addendums, Questions and
Answers can all be accessed once your login to the Purchasing website at
www.stockton.edu/purchasing . It is the responsibility of the Respondent to
monitor the website for any changes, additions, clarifications, cancellations
etc. as related to this RFP.
Use of the internet has proven to be the most efficient medium for
communication with potential Respondents. It is by no means intended by
the College to be exclusionary. If internet access is not available to an
interested Respondent, the College will take alternate methods of
communication measures to ensure all Respondents have an equal
opportunity to submit a complete proposal. The Respondent must
immediately provide the College in writing with an alternative method of
communication such as the firm’s fax number or mailing address
(“Alternative Method of Communication”).
4
1.3
Rejected Proposal:
The College reserves the right to reject any or all proposals or to award in
whole, or in part, if deemed to be most advantageous to the College.
1.4
Cost Liability:
The College assumes no responsibility and no liability for costs incurred by
respondent firms prior to issuance of any agreement, contract, or purchase
order.
1.5
Mandatory Pre-Bid Meeting:
There will be a mandatory pre-bid meeting held on Wednesday, May 15,
2013 on the main campus in F-Wing Room 118 at 9AM.
1.6
Questions and Inquiries:
All questions and/or inquiries must be submitted by email or fax to Annette
Hamm at [email protected]. or faxed questions may be sent
to (609)626-3801. Please reference the bid number B130022. The deadline
for questions is Monday, May 20, 2013 by 10:00 a.m.
1.7
Revisions to the Request for Proposal:
In the event it becomes necessary to revise any part of this RFP, revisions
will be advertised and posted on the website. Respondents will be
required to acknowledge the receipt of the addendum, if any, on the bid
document checklist.
1.8
Response Date:
In order to be considered, proposals must arrive at the Purchasing Office of
the College no later than 2:00 p.m. (E.D.T.) on Tuesday, May 28, 2013 at
which time the Respondent’s proposals to this request will be publicly read
aloud. Proposals should indicate/reference Bid Number B130022 on the
front of the envelope to distinguish it form other bids received by the
College.
1.9
Mailing Instructions:
The Richard Stockton College assumes no responsibility for unmarked
envelopes. Nor will the College be responsible for the failure to deliver any
bid by USPS, Fed Ex, UPS or any other carrier/mail service. It is the
responsibility of the vendor to ensure timely delivery of your bid. The time
5
for the submittal of bids is firm. No proposals will be accepted after the
specified time and date.
Sealed proposals are to be submitted to:
The Richard Stockton College
Purchasing Dept. Bldg. 70 Plant Mgmt.
101 Vera King Farris Drive
Galloway, NJ 08205
1.10
Qualification of Respondents:
Respondents shall be of known reputation and shall have sufficient qualified
personnel and equipment to perform adequately the prescribed service as per
specifications. As evidence of these qualifications, Respondents should
submit the following information with their proposals by completing the
Summary Information Sheet known as “Attachment A” containing the
information listed below and return said sheets with their proposal.
Statements such as “see previous proposals or lists submitted” are not
acceptable and may be cause for proposals to be considered non-responsive.
1.
2.
3.
4.
5.
6.
All Respondents shall have five (5) years experience and shall be
experienced in installing, integration, or assembling work similar in
material, and extent to that indicated for this project, whose work has
resulted in construction with a record of successful in service
performance.
Location of the Respondent’s office that will be responsible for
managing this contract. Include phone number, fax number, cell
phone number and e-mail address.
Name(s) and phone number(s) of management personnel to be
contacted if problems or emergencies occur.
A list of New Jersey State Agencies, US Governmental Agencies,
public and private universities now under contract with the
Respondent’s firm.
A listing of three (3) references where similar systems were
installed. Provide the name, title, and telephone number of an
individual at each reference site who can provide an independent
assessment of the Respondent’s performance.
A list of contracts the Respondent firm has lost during the last three
years with the reason the contract was terminated for each job.
6
1.11
Acceptance of Proposal Content:
Contents of the proposal of the successful Respondent will become a part of
any contract awarded as a result of this RFP.
1.12
Proposal Instructions:
1.12.1 For purposes of this RFP, the College has endeavored to address all
services.
1.12.2 Proposal should be prepared simply and economically providing a
straightforward, concise description of the vendor’s capabilities to
satisfy the requirements of this RFP. Emphasis should be on
completeness and clarity.
1.12.3 The RFP cover sheet shall indicate a total bid price for the purchase
of all necessary materials and installation costs to complete the
project. The RFP cover sheet must contain an original signature
of an individual authorized to bind the company. Failure to
meet this requirement is grounds for rejection of the
Respondent’s proposal as non-responsive.
1.13
Prime Respondent’s Responsibilities:
The selected vendor will be required to assume sole responsibility for the
complete effort as defined by this RFP. The College will consider the
selected vendor to be the sole point of contact with regard to all contractual
matters.
1.14
Subcontracting:
Any contract awarded pursuant to this RFP shall not be subcontracted
without the prior written approval from the Vice President for
Administration and Finance to any other person, company, corporation,
firm, organization or agency.
At the time of proposing, the Respondent shall submit a list of subRespondents, the type of work performed, and other pertinent data so
as to qualify the sub Respondent’s capabilities. To the extent that the
Respondent engages sub Respondents or sub-consultants to perform services
under this contract, the Respondent must demonstrate that a good faith effort
was made to utilize sub Respondents or sub-consultants who are registered
with the NJ Division of Minority and Women Business Development as
SBEs, as more fully described on Appendix C of Executive Order 151 and
made part of this agreement as Exhibit A”. The successful Respondents
7
shall submit proof of sub Respondents’ and sub-consultants’ SBE
registration and efforts to utilize SBE sub Respondents and sub-consultants
as part of the contract documents and shall complete such other forms as
may be required by the College for State reporting of participation.
1.15
Assignment:
The Respondent is prohibited from assigning, transferring, conveying,
subletting or otherwise disposing of the agreement or its right, title or
interest therein of its power to execute such agreement to any other person,
company or corporation without the previous written consent and approval
by the Vice President of Administration and Finance.
1.16
Stockholders Disclosure:
During the entire term of the contract, the successful Respondent must
immediately notify the College of all changes of Colleges, partners,
directors, officers, and indirect Colleges of the firm. The Ownership
Disclosure Form must accompany this proposal.
1.17
Price Terms:
1.17.1 No Respondent may withdraw his/her bid proposal within sixty (60)
days after the actual date of the opening thereof. All prices are firm.
Verify with manufacturers availability and cost of all equipment
proposed, including equipment specified herein. No cost increases
will be allowed for manufacturers’ cost increases, or for substitutions
required because of unavailability of proposed equipment.
1.17.2 The successful Respondent shall assume all liability and
responsibility for the delivery of merchandise in good condition to
the College.
1.17.3 Change orders will not be allowed for Respondent error in
estimating the cost of the Project. Carefully examine the contract
documents and the campus to obtain first-hand knowledge of
existing conditions. Respondents will not be given extra payments
for conditions that can be determined by examining documents or
site and will not be relieved of any obligations with respect to the
bid.
1.17.5 The RFP cover sheet shall indicate the total price for a turn-key
project representing the purchase of all materials, delivery, and costs
of labor necessary to complete the project. In addition, provide a
hourly cost for additional training (See Exhibit B – Scope of Work
Section 1.7 Training.) Any corrections must be “whited out” and
initialed in ink. Proposals containing pencil will be rejected.
1.17.6 You may bid an equivalent or better for the brand name
specified. All requests for substitutions from these specifications
8
must be submitted on the attached forms known as Attachment
B at the time of the bid. All substitutions will be reviewed by the
College. The College will issue a final decision on the equivalency
of the product(s).
If the proposed substitution of specified product is rejected, the
Respondent shall be required to provide the specified products.
Consideration:
A request for substitution is a representation by the Respondent that:
The Respondent has personally investigated the proposed
substitution and determined that it is equal or superior in all respects
to that specified.
The Respondent will provide the same warranty for the substitution
that would be for that specified.
The cost data presented are complete and include all related costs
under this Contract, but exclude costs under separate contracts and
exclude Architect's re-design costs, and that the Respondent waives
all claims for additional costs related to the substitution which
subsequently become apparent.
The Respondent will coordinate the installation of the accepted
substitute, making such changes as may be required for the Work to
be complete in all respects.
1.18
Payment Process:
Application for Payments shall be based on the approved Schedule of
Values. The submission and approval of progress updates calculating the
value of Work done for any given pay period for any activity based on the
percentage complete for that activity less the amount previously paid for
past percentages complete and percent of retainage shall be an element of
the evaluation of progress payments. An initial application for payment for
expenditures not directly related to the Work accomplished at the project
will be allowed before the acceptance of the Respondent’s Progress
Schedule. Requests for payment for Work items not included above may be
denied without an approved schedule.
The College may make progress payments monthly as the Work proceeds,
or at more frequent intervals as determined by the College, on estimates
approved by the College. Unless otherwise directed, the Respondent shall
furnish a schedule of amounts for contract payments of the total contract
9
price, showing the amount included therein for each principal category of
the Work, in such detail as requested, to provide a basis for determining
progress payments. The schedule, as approved, shall be used only as a basis
for the Respondent's estimates for progress payments, and approval by the
College does not constitute acceptance of the allowability of costs to a
specific element of Work. The Respondent is cautioned that no payment
requests shall be approved until the Schedule of Values, (SOV) has been
approved in writing by the College’s authorized representative. In making
such progress payments for contract Work completed, the College will
retain ten percent (10%) of the approved invoice amount until Substantial
Completion of all Work covered by the contract.
If performance or payment bonds are required under this Contract, the
College shall pay to the Respondent the total premiums paid by the
Respondent to obtain the bonds. This payment shall be paid at one time to
the Respondent together with the first progress payment otherwise due after
the Respondent has (1) furnished the bonds (including coinsurance
and reinsurance agreements, when applicable), (2) furnished evidence in full
payment to the surety company, and (3) submitted a request for such
payment. This payment of the bond premiums by the College to the
Respondent shall not be made as increments of the individual
progress payments and shall not be in addition to the contract price.
Upon completion and acceptance of all Work, the amount due the
Respondent under this Contract shall be paid upon satisfactory completion,
by the Respondent, of all contract closeout requirements, completion of an
audit on all contract values and payments, and after the Respondent has
furnished the College with a release of claim against the College, arising by
virtue of this Contract, other than claims in stated amounts as may be
specifically excepted by the Respondent from the release.
Upon satisfying the above conditions, the Respondent shall submit a
properly executed invoice for final payment to the College project
representative who will initiate the process of final payment review and
approval.
1.19
Review of Respondent Claims and Disputes:
1.19.1
Upon presentation by the Respondent of a request in writing, the
College may review any decision or determination of the RSC
representative or the A/E as to any claim, dispute or any other
matter in question relating to the execution or progress of the Work
or the interpretation of the Contract Documents.
Consistent with the intent of this Contract, the College may
schedule a conference for the purpose of settling or resolving such
10
claims, disputes or other matters. Where such a conference is
conducted, the Respondent shall be afforded the opportunity to be
heard on the matter in question.
Following review of the Respondent's request, the RSC and the
Respondent may settle or resolve the disputed matter, provided
however that any such settlement or resolution shall be subject to
all requirements imposed by law, including where applicable, the
New Jersey Contractual Liability Act (NJSA 59:13-1 et seq.).
1.19.2
1.20
Unsettled Claims and Dispute shall be processed in accordance
with the procedures stated in the Purchasing Procedures Manual.
Termination
1.20.1
The College may, at any time, terminate the Contract in whole or
in any part for the RSC’s convenience and without cause when
the College in his/her sole discretion views termination is in the
public interest.
1.20.2
Upon receipt of an order of Termination for Convenience, the
Respondent shall not proceed with any item of Work, which is not
specified in the Order of Termination. The Respondent shall
complete all items of Work specified in the Termination order.
Such Work shall include punch list items and all Work necessary
to ensure the safety of the public, to properly secure existing
Work already constructed or partially constructed and to secure
the Project site.
This Work so ordered shall be performed in accordance with the
Contract Documents, and may include items of Work not in the
original Contract. The Contract shall be considered substantially
complete upon completion and acceptance of all items of Work
specified in the Order, except punch list items. After completion
of the punch list items and all documents required by the
Contract, the Contract shall terminate upon issuance of a Final
Certificate and Payment. The College reserves the right to
declare in default a Respondent whom fails to carry out the
conditions set forth in an Order of Termination for Convenience.
When the RSC orders termination of the Contract for
Convenience, all completed items of Work as of that date will be
paid for at the Contract price. Payment for partially completed
Work will be paid for at agreed prices. Items which are
eliminated in their entirety by such termination will be paid for
only to the extent provided in Paragraph 1.20.3.
11
Materials obtained by the Respondent for the Work but which
have not been incorporated therein may, at the option of the RSC,
be purchased from the Respondent at actual cost delivered to a
prescribed location, or otherwise disposed of as mutually agreed.
Within 60 days of the effective termination date, the Respondent
shall submit claims for additional costs actually incurred, not
covered above or elsewhere in the Contract. Such claims may
include such cost items as reasonable mobilization efforts,
overhead expenses attributable to the Work performed, and sub
Respondent costs not otherwise paid for, actual idle labor cost if
Work is stopped in advance of the termination date. Costs, which
are prohibited under provisions of the Contract and anticipated
profits on Work not performed, are not allowed.
1.20.3
If acceptable material is ordered by the Respondent for the
eliminated item prior to the date of notification of such
elimination and if orders for such material cannot be canceled, it
will be paid for at the actual cost to the Respondent. In such case,
the material paid for becomes the property of the RSC and the
actual cost of any further handling will be paid for. If the material
is returnable to the vendor and if the RSC so directs, the material
shall be returned and the Respondent will be paid for the actual
cost or charges made by the vendor for returning the material.
The actual costs of handling returned material will be paid.
The actual costs or charges will be computed in the same manner
as if the Work were to be paid for as provided in the Contract.
However, no profit will be allowed.
1.20.4
Post Termination Obligations
1. Cancel, or if so directed by the RSC, transfer to the RSC all or
any of the commitments and agreements made by Respondent
relating to the Project, to the extent same are cancelable or
transferable by Respondent.
2.
Transfer to the RSC the manner, to the extent, and at the time
directed by the RSC, all supplies, materials, and other property
produced as a part of, or acquired in the performance of,
Respondent’s services in connection with the Project; and
3.
Take such other actions as the RSC may reasonably direct.
12
1.21
Ownership of Materials:
Ownership of all data, material and documentation originated and prepared
for the College pursuant to this RFP and ensuing contract shall become and
remain the property of the College.
1.23
Performance and/or Delivery of Service:
Any information deemed by the College to be most advantageous to the
College regarding the ability of the Respondents to supply and/or render the
required services may be taken into consideration in making an award.
1.24
Indemnification:
The Respondents shall indemnify, defend, and hold harmless the Richard
Stockton College, its Board of Trustees, directors, officers, employees,
servants and agents from and against all claims, damages, losses suits,
actions, judgments, costs, and expenses, including reasonable attorneys’
fees, costs and expenses sustained by Richard Stockton College or third
parties to the extent such damage or injury is attributable in whole or in part
to any negligent acts, errors or omissions of the Respondent in the
performance of its services hereunder, or that of any subcontractor retained
by the Respondent, and shall procure and maintain insurance covering its
contractual obligations hereunder.
The College, is a State entity under and subject to the provisions of N.J.S.A.
18A:64-1 et. seq. is prohibited from providing an indemnification. Any
agreement signed on behalf of the State of New Jersey by a State official
shall be subject to all of the provisions of the New Jersey Tort Claims Act
(NJSA 59:1-1 et seq.), the New Jersey Contractual Liability Act (NJSA
59:13-1 et seq.), and the availability of appropriations.
The State of New Jersey does not carry public liability insurance, but the
liability of the State and the obligation of the State to be responsible for tort
claims against its employees is covered under the terms and provisions of
the New Jersey Tort Claims Act.
The Act also creates a fund and provides for payment of claims under the
Act against the State of New Jersey or against its employees for which the
State is obligated to indemnify against tort claims, which arise out of the
performance of their duties.
Claims against the State of New Jersey or its employees should be referred
to the State of New Jersey, Bureau of Risk Management, PO Box 620,
Trenton, NJ 08625
13
The exclusive jurisdiction for all claims brought against Richard Stockton
College, is the Federal District Court or State Superior Court venued in State
of New Jersey.
1.25
Insurance:
1.22.1
The Bidder, Consultant, or Contractor shall be liable to The
Richard Stockton College (the College), its employees, officers
and agents for any direct or consequential losses, and any injury
including bodily injury, death, damages to or destruction of
physical property, resulting, in whole or in part, from any
negligent acts, errors or omissions of the Bidder, Consultant or
Contractor in the performance of its services. In addition, the
successful Bidder, Consultant and/or Contractor agrees to hold
the College harmless from any and all causes of loss and claims
arising from this contract. The College prohibits capping
liability to anything less than the liability insurance coverage.
1.22.2
The successful Bidder, Consultant and/or Contractor shall
procure, and require its contractors and consultants to procure,
prior to the commencement of services, and maintain, at its own
expense, until final acceptance by the College of all services
required under the Agreement, insurance for liability for
damages imposed by law and assumed under the Agreement, of
the kinds and in the amounts hereinafter provided, with insurance
companies authorized to do business in the State of New Jersey.
The insurance carriers shall have a Best’s Rating of "B+" or
better.
All of the policies of insurance required to be purchased and
maintained and the certificates, declaration pages, or other
evidence thereof shall contain a provision or endorsement that
the coverage afforded is not to be cancelled, materially changed
or non-renewed without at least 30 days prior written notice to
the College by certified mail.
All such policies shall name The Richard Stockton College of
New Jersey and the State of New Jersey as "Additional Insured".
1.22. 3
The Bidder, Consultant and/or Contractor shall furnish to the
College, within ten (10) days of the effective date of this
Agreement, Certificates of Insurance, together with declaration
pages, in a form satisfactory to the College, evidencing that it has
14
complied with this Subsection. The required Certificate of
Insurance shall be filed with the College and same will be made
part of the contract.
No work shall commence until the insurance requirements and
Certificate for same are on file. All required insurance coverage
must be in effect no later than 12:01 a.m. at the start of the day of
the contract and shall remain in effect for the duration of the
contract, including any extensions thereto, and for ninety (90) days
following termination of all work.
1.22.4
The successful Bidder, Consultant and/or Contractor shall procure
and maintain the below listed types of insurance with limits of
liability in at least the amounts also listed below and the College
shall be named as an "Additional Insured" on those policies
required under subsections A. and B. :
A. Commercial General Liability Insurance. The minimum limit of
liability shall be $1,000,000 per occurrence (combined single limit
for bodily injury and property damage)/$3,000,000 aggregate,
including products/completed operations and contractual liability
insurance.
B. Comprehensive Automobile Liability Insurance. The policy
shall cover owned, non-owned, hired, leased and rented vehicles
with minimum limits of liability in the amount of $1,000,000. per
accident as a combined single limit for bodily injury and property
damage.
C. Workers Compensation and Employer's Liability Insurance.
Worker's Compensation and Employer's Liability insurance shall
be provided in accordance with the requirements of the laws of
New Jersey.
1.26 Proposal Security:
A bid bond of 10% (ten percent) of your bid not to exceed $20,000 is to be
included with the submission of your proposal
1.27 Performance Bond:
1.27.1
Within 10 days of the notice of award, the Respondent shall
complete and deliver a Performance Bond and a Payment Bond as
15
required herein and by and subject to the New Jersey Public Works
Bond Act, N.J.S.A. 2A:44-143 et seq.
Each bond shall be for a sum of not less than the total Contract Price.
In the event of insolvency of the surety, the Respondent shall
forthwith furnish and maintain, as above provided, other surety
satisfactory to the College.
1.27.2 All alterations, extensions of Contract Time, extra and additional
work, and other changes authorized by the Contract Documents may
be made without securing the consent of the surety or sureties of the
bonds.
1.27.3 The surety corporation bonds shall be furnished by only those
sureties listed in the US Treasury Department Circular 570 and
authorized to do business in the State. The bonds shall be
accompanied by a certification as to authorization of the attorney-infact to commit the surety company and a true and correct statement
of the financial condition of said surety company.
1.28 Other Licenses/ Permits/Documents:
The Respondent shall be required to obtain and maintain during the term of
the contract, all licenses, permits, authorizations, or any document required
by Federal, State, County and Municipal governments and
agencies/authorities thereof, so that he/she may conduct the requirements
necessary to perform the contract.
The Respondent shall, upon request, supply the College evidence that such
licenses, permits, authorizations or other required documents have been
obtained.
1.29 Prevailing Wages:
The New Jersey Prevailing Wage Act P.L. 1996 Chapter 150 is hereby made
a part of every contract entered into on behalf of the College, except those
contracts which are not within the contemplation of the Act. The
Respondent’s signature on the proposal serves as their guarantee that neither
he/she nor any sub Respondents he/she may employ to perform the work
covered by this proposal are listed or are on record in the Office of the
Commissioner of the Department of Labor and Industry as one who has failed
to pay prevailing wages in accordance with the provisions of the Act.
Provisions of the act include the following stipulations and requirements:
16
All Workers employed in the performance of every contract in which the
contract sum is in excess of $2,000 and to which the RSC is a party shall be
paid not less than the prevailing wage rate as designated by the Commissioner,
Department of Labor or his or her duly authorized representative.
1)
Each Respondent and sub Respondent performing public work for
the RSC and which is subject to the provisions of the Prevailing
Wage Act, shall post the prevailing wage rates for each craft and
classification involved as determined by the Commissioner,
Department of Labor. This posting shall include the effective date of
any changes thereof, and shall be displayed in prominent and easily
accessible places at the site of the work or at such place or places as
are used by the Respondent/sub Respondent to pay workers' wages.
(2)
At the time of the bid due date, the bidder and the sub Respondents
must be registered in accordance with “The Public Works
Respondent Registration Act” (N.J.S.A. 34:11-56.48 et seq.) All
questions regarding registration should be addressed to:
Respondent Registration Unit
New Jersey Department of Labor
Division of Wage and Hour Compliance
P O Box 389
Trenton, New Jersey 08625-0389
Telephone: 609-292-9464
Fax: 609-633-8591
In the event it is found that any worker, employed by any Respondent or sub
Respondent covered by any contract in excess of $2,000 for any public work to
which the RSC is a party, has been paid a rate of wages less than the prevailing
wage required by such contract, the RSC may terminate the Respondent's or
sub Respondent’s right to proceed with the Work, or such part of the Work as
to which there has been failure to pay required wages, and may otherwise
prosecute the Work to completion.
Nothing contained in the Prevailing Wage Act shall prohibit the payment of
more than the prevailing wage rate to any worker employed on a public work.
2.0
Scope of Work:
The key vision of the Communications Studies Program at the College is to
become a strong and competitive program in the region. In order to
accomplish this goal, the program needs the highest equality equipment and
software so that students can gain experience with the most current
technology.
17
The present condition of the TV studio equipment can be termed “functional
but near obsolete”. The College seeks to upgrade this equipment to HD
platform.
The work consists of the fabrication, purchase, installation, integration,
training and maintenance of the specified TV Studio equipment (See Exhibit
B – Scope of Work and Exhibit C – Equipment List). See the attached
drawing for the layout of the studio (Room E034).
2.1
Special Considerations:

2.2
The project will commence upon a duly awarded contract with project
completion August 2013.
Supervision, Installation Procedures, Respondent Personnel
The Respondent shall provide the following installation services:
2.2.1
The Respondent shall be responsible for keeping grounds, walks,
corridors and material stockpiles neat and orderly at all times. Any
unsightly, unsanitary and/or hazardous conditions shall be corrected
as soon as possible. All areas shall be returned to the condition they
are found; no packing materials or debris is to be left in any building
or on site. Respondent must provide their own dumpster for all trash
removal.
2.2.2
Performance and completion of work shall be in accordance with the
work schedule developed with the
2.2.3
Supervision and direction of the work site responsibility for all
construction means, methods, techniques, sequences and procedures
and for coordination of all portions of the work under the contract.
2.2.4
All personnel must observe all regulations then in effect at the
College. While on College property, employees shall be subject to
control of the College, but under no circumstances shall such persons
be deemed to be employees of the College. The Vendor or its
personnel shall not represent themselves as employees of the
College.
2.2.5
The Respondent shall supply all materials and tools necessary to
perform its services.
18
3.0
Proposal Evaluation
3.1
Proposals shall be judged on price and other factors, pursuant to N.J.S.A.
18A:64-6 (w) based on the following criteria:
1) The experience and qualifications of the Respondent based on the
information submitted in written proposal.
2) The ability to efficiently, accurately and successfully perform these
services is considered essential. The Respondent’s prior history with
regard to these services will be used in determining whether the
Respondent is considered responsible and whether the award of the
contract is most advantageous to the College.
3) Whether the Respondent responds to all specification requirements, in
sufficient detail for the evaluator(s) to analyze the proposal and make
sound judgments about it.
4) The training, certifications, and any other qualifications that
differentiate one Respondent from another.
4.0
Additional General Conditions of the Contract
The following additional General Conditions shall apply to the Contract awarded
hereunder:
4.1
Law Against Discrimination
Compliance with the requirements of P.L. 1975, c. 127 (N.J.A.C. 17:27)
(Law Against Discrimination in Public Contracts) and throughout the
contract term.
4.2
Business Registration
Compliance with the requirements of P.L. 2004, c. 57 et seq. (Business
Registration) and throughout the contract term. The firm understands
that failure to abide by the requirements of this statute and to continue to
do so, constitutes a material breach of contract in the award or
performance of this contract such that the firm may be disqualified or
payments pursuant to the contract may be withheld until compliance is
perfected.
Further the firm agrees to advise in writing any sub Respondents
of the need to comply with this requirement. The firm shall maintain a
current list of such sub Respondents and their addresses and shall submit
the list with its proposal and as needed by the College during the course of
19
performance of this contract. The firm shall provide with its proposal a
copy of its valid Business registration certificate, pursuant to P.L. 2004, c.
57 and ensure that such registration remains in effect throughout the period
of this contract. The firm agrees to notify the College if at any time its
Business Registration becomes invalid.
Further, the firm agrees to procure from any sub Respondent’s proof of
compliance with the Act prior to performing any services pursuant to this
contract. Should firm or any sub Respondents fail to maintain a valid
registration they understand that RSC is prohibited from issuing payments
under this contract until a valid registration is obtained.
4.3
Political Contributions Disclosure
The firm will supply the completed disclosure forms as part of its proposal
so it is compliant with the Requirements of Public Law 2005, Chapter
51(N.J.S.A.19:44A-20.13-20.25) “Political Activity Disclosure”, dated
September 22, 2004 and any statutes or regulations which result thereof. The
firm understands the College is prohibited from awarding this contract or
issuing payments until the State Treasurer or his designee gives approval
that the requirements of the Public Law have been met.
If awarded the contract, the firm agrees during the course of this contract
that it remains compliant with Public law, Chapter 51.and to notify the
College if at any time it is no longer compliant.
The firm understands that failure to abide by the requirements of this
statute and to continue to do so, constitutes a material breach of contract in
the award or performance of this contract such that the firm may be
disqualified or payments made pursuant to this contract may be withheld
until compliance is perfected.
20
ATTACHMENT A
SUMMARY INFORMATION SHEET
FIRM NAME: _______________________________________________________________________________________
1. YEARS OF EXPERIENCE IN INSTALLING, INTEGRATION, OR ASSEMBLING WORK SIMILAR IN MATERIAL, AND EXTENT
TO THAT INDICATED FOR THIS PROJECT: __________________________________________________
2. CONTACT/LOCATION OF THE RESPONDENT’S OFFICE THAT WILL BE RESPONSIBLE FOR MANAGING THIS CONTRACT:
NAME: __________________________________________________________________________________________
TITLE: __________________________________________________________________________________________
ADDRESS: ______________________________________________________________________________________
______________________________________________________________________________________
PHONE: ________________________________________ FAX: _________________________________________
CELL PHONE: ____________________________________ EMAIL: _______________________________________
3. NAME(S) AND TELEPHONE NUMBER(S) OF MANAGEMENT PERSONNEL TO BE CONTACTED IF PROBLEMS OR
EMERGENCIES OCCUR: _____________________________________________________________________________
__________________________________________________________________________________________________
CURRENT CONTRACTS
4. PLEASE LIST THE NEW JERSEY AGENCIES, US GOVERNMENTAL AGENCIES, PUBLIC AND PRIVATE UNIVERSITIES
NOW UNDER CONTRACT WITH THE RESPONDENT FIRM: ___________________________________________________
____________________________________________________________________________________________________
____________________________________________________________________________________________________
5. PLEASE LIST REFERENCES WHERE SIMILAR TYPE SERVICES WERE PROVIDED. PROVIDE THE NAME, TITLE, AND
TELEPHONE NUMBER OF AN INDIVIDUAL AT EACH REFERENCE SITE WHO CAN PROVIDE AN INDEPENDENT
ASSESSMENT OF THE PROPOSER’S PERFORMANCE:
COMPANY NAME: _______________________________________________________________________________________
NAME/TITLE: ________________________________________________ TEL.#: ____________________________________
COMPANY NAME: _______________________________________________________________________________________
NAME/TITLE: ________________________________________________ TEL.#: ____________________________________
COMPANY NAME: _______________________________________________________________________________________
NAME/TITLE: ________________________________________________ TEL.#: ____________________________________
6. PLEASE LIST CONTRACTS THE RESPONDENT HAS HAD TERMINATED DURING THE LAST THREE YEARS WITH THE
REASON THE CONTRACT WAS TERMINATED FOR EACH JOB. IF NONE, INDICATE SO:
TERMINATED CONTRACT: _______________________________________________________________________________
TERMINATED CONTRACT: _______________________________________________________________________________
TERMINATED CONTRACT: _______________________________________________________________________________
21
ATTACHMENT B
VENDOR SUBSTITUTION REQUEST FORM
BID: ___________________________
The undersigned, as contractor for the above BID, requests that the following product be accepted for use
By the College:
PRODUCT: __________________________________________________________________________
PART NO: _________________________________________________________________________
MANUFACTURER:
__________________________________________________________________
ADDRESS: __________________________________________________________________________
The above product would be used in lieu of
PRODUCT: __________________________________________________________________________
specified in
ATTACHMENT : ___________________________________________________________________________-
Reason for substitution request: _____________________________________________________________
_______________________________________________________________________________________
Attached are the following circled items:
1. Product description including specifications, performance and product data sheets including installation and
warranty, and applicable reference standards.
2. Drawings
3. Samples
4. Tabulated comparison with specified product.
5. For items requiring color selections, full range of manufacturer’s color samples.
6. Documentation of reason for request.
7. Cost data for comparing proposed substitution with specified product.
8. Other:_____________________________________________________________________________
The undersigned certifies that the following statements are correct. Explanations for all items which are not true
are attached.
1. Proposed substitution has been thoroughly investigated and function,
and quality meet or exceed that of specified product.
TRUE FALSE
2. Same warranty will be provided for substitution as for specified product.
TRUE FALSE
Vendor Substitution Request Form
1
22
ATTACHMENT B
VENDOR SUBSTITUTION REQUEST FORM
3. No aspect of Project will require re-design.
TRUE FALSE
4. Use of substitution will not adversely affect:
a. The existing surface.
TRUE FALSE
b. Installation schedule and date of completion.
TRUE FALSE
c. Work of other trades.
TRUE FALSE
5. Proposed substitution will meet the project timeline.
TRUE FALSE
6. All changes to Contract Sum related to use of proposed
substitution are included in price listed below. Vendor
waives claims for additional costs related to acceptance of
substitution which may subsequently become apparent.
TRUE FALSE
7. Costs of any tests caused by use of proposed
substitution will be paid for by the Contractor.
TRUE FALSE
If substitution request is accepted:
Contract Sum will be [decreased] [increased] by $ __________________________________________
Contract Time will be [decreased] [increased] by _________________________________ calendar days.
Submitted by:
VENDOR: ____________________________________________________________________
ADDRESS: ________________________________________________________________________
TELEPHONE NUMBER: _____________________________________________________________
NAME OF PERSON SUBMITTING REQUEST: __________________________________________
TITLE: ____________________________________________________________________________
DATE: ____________________________________________________________________________
Vendor Substitution Request Form
2
23
EXHIBIT A
Executive Order 151
APPENDIX C
It is the policy of the Richard Stockton College of New Jersey that small businesses (each a “small business
enterprise” or “SBE”), as determined and defined by the State of New Jersey, Division of Minority and Women
Business Development (“Division”) and the New Jersey Department of the Treasury (“Treasury”) in N.J.A.C.
17:14 et seq. or other application regulation, should have the opportunity to participate in [Reporting Agency]
Contracts.
To the extent the Firm engages subcontractors or sub-consultants to perform Services for the Richard Stockton
College of New Jersey pursuant to this Contract, the Firm must demonstrate to the Richard Stockton College of
New Jersey satisfaction that a good faith effort was made to utilize subcontractors and sub-consultants who are
registered with the Division as SBEs. Furthermore, the Reporting Agency shall be evaluated quarterly by the
Division, based on its attainment of the Participation Goals set forth in the State of New Jersey Construction
Services Disparity Study (October 2005) and the State of New Jersey Disparity Study of Procurement in
Professional Services, Other Services, and Goods and Commodities (June, 2005). (These participation goals are
set forth below.)
Evidence of a “good faith effort” includes, but is not limited to:
1. The Firm shall request listings of SBEs from the Division (609) 292-2146 and/or the Richard Stockton
College of New Jersey and attempt to contact same.
2. The Firm shall keep specific records of its efforts, including records of all requests made to the Division,
the names of SBEs contacted, and the means and results of such contacts, including without limitation
receipts from certified mail and telephone records.
3. The Firm shall actively solicit and shall provide the Richard Stockton College of New Jersey with proof of
solicitations of SBEs for the provision of Services, including advertisements in general circulation media,
professional service publications and small business, minority-owned business or women-owned business
focus media.
4. The Firm shall provide evidence of efforts made to identify categories of Services capable of being
performed by SBEs.
5. The Firm shall provide all potential subcontractors and sub-consultants that the Firm has contacted
pursuant to 2 or 3 above with detailed information regarding the scope of work of the subject contract.
6. The Firm shall provide evidence of efforts made to use the goods and/or services of available community
organizations, consultant groups, and local, State, and federal agencies that provide assistance in the
recruitment and placement of SBEs.
Furthermore, the Firm shall submit proof of its subcontractors’ and/or sub-consultants’ SBE registrations on the
Notice of Intent to Subcontract form, and shall complete such other forms as may be required by the Richard
Stockton College of New Jersey for State reporting as to participation.
Participation Goal: Refer to Appendix D
Appendix D
Consistent with the findings of the State of New Jersey Construction Services Disparity Study (October 2005) and
the State of New Jersey Disparity Study of Procurement in Professional Services, Other Services, and Goods and
Commodities (June 13, 2005), each Reporting Agency should aspire to allocate a portion of its total contracting
dollars in accordance with the following goals.
1. Construction Services Contracts/Subcontracts (including new construction and renovations, except routine
building maintenance; residential and non-residential building construction; heavy construction, such as streets,
roads and bridges; and special trade construction, such as fencing, HVAC, paving and electrical).
State Agencies/Authorities/Commissions/Colleges and Universities
African Americans -- 6.3%
Asian Americans -- 4.34%
Caucasian Females -- 12.67%
24
EXHIBIT A
Executive Order 151
2. Construction-Related Services Contracts/Subcontracts (including design services, such as architectural,
engineering and construction management services, that are performed as part of a construction project).
State Colleges and Universities
African Americans -- 4.51%
Asian Americans -- 7.11%
Hispanics -- 4.09%
3. Professional Services (with the exception of those professional services deemed to be construction-related, all
services that are of a professional nature and requiring special licensing, education degrees and/or very highly
specialized expertise, including accounting and financial services, advertising services, laboratory testing
services; legal services; management consulting services; technical services and training).
State Agencies/Authorities/Commissions/Colleges and Universities
African Americans -- 2.47%
Asian Americans -- 1.47%
Hispanics -- 1.1%
Native Americans -- 0.07%
Caucasian Females -- 3.74%
4. Other Services (any service that is labor-intensive and neither professional nor construction-related, including,
but not limited to equipment rental; janitorial and maintenance services; landfill services; laundry and dry
cleaning; maintenance and repairs; printing; real property services; security services; special department supplies;
subsidy, care and support; telecommunications; and temporary help).
State Agencies/Authorities/Commissions/Colleges and Universities
African Americans -- 1.22%
Asian Americans -- 0.85%
Hispanics -- 0.67%
Native Americans -- 0.05%
Caucasian Females -- 1.96%
5. Goods and Commodities (equipment and consumable items purchased in bulk, or a deliverable product
including, but not limited to automobiles and equipment; chemicals and laboratory supplies, construction
materials and supplies; equipment parts and supplies; fuels and lubricants; janitorial and cleaning supplies; office
equipment; office supplies; radio equipment; special department supplies; technical supplies; tires and tubes;
traffic signals; and uniforms).
State Agencies/Authorities/Commissions/Colleges and Universities
African Americans -- 2.71%
Asian Americans -- 1.74%
Hispanics -- 1.32%
Native Americans -- 0.10%
Caucasian Females -- 4.45
25
January 19, 2013
TV Studio Communication Equipment
Richard Stockton College of New Jersey
EXHIBIT B SCOPE OF WORK
B130022
1.1
SCOPE OF WORK
A.
The work consists of the provision of all plant, materials, labor and equipment and the like
necessary and/or required for the complete execution of all audiovisual equipment and related
work for this project as required by the schedules, keynotes and drawings, including, but not
limited to the following:
1.
Unless otherwise specified, supply only new equipment, parts and material, and protect
all equipment from construction dust and debris until final acceptance. Operate only as
required for testing as part of installation procedure. Provision of all manufactured
components, installation, wiring, and testing is the responsibility of a single contractor.
2.
Included herein is a recommended equipment list. Items could be substituted as equal,
with approval by the College. The system drawings indicate the general layout of the
various items of equipment and their functional relationships. However, layout of
equipment, accessories, and conduit systems are diagrammatic unless specifically
detailed and do not necessarily indicate every item required for a complete installation.
Provide any incidental equipment needed in order to result in a complete and operable
system even if not specified or shown on drawings without claim for additional
payment. The equipment list represents a minimum complement for an HDTV studio
and we recognize it may require additions or changes to complete the vendor specified
HDTV system. The recommended equipment list provides the college with a complete
system with operational characteristics that will conform well to teaching and should
meet faculty expectation, while maintaining broadcast quality.
3.
Quantities of all major installed and all portable equipment are indicated on the
schedules. Quantities of portable equipment are indicated in schedules contained
specifications.
4.
Refer to audiovisual conduit drawings for receptacle back box location and quantity
information. Also refer to architectural reflected ceiling plans for exact location of
ceiling-mounted devices.
5.
Verify correctness of parts lists and equipment model numbers and conformance of
each component with manufacturer's specifications.
6.
Obtain all permits necessary for the execution of the work. Comply with all applicable
state and local codes and regulations.
B.
Functional Requirements of Systems:
1.
a.
Provide a complete turn-key professional broadcast level television studio system
with high quality, capability, and industry sophistication High Definition (HD)
equipment.
b.
Provide HD field camera equipment
1
26
January 19, 2013
1.2
TV Studio Communication Equipment
Richard Stockton College of New Jersey
QUALITY ASSURANCE
A.
Project Management: Maintain the same person in charge of work throughout installation.
B.
Contract Documents: Maintain a complete set of system drawings and specifications at the
site at all times during installation.
C.
Fabrication and Installation: Fabricate all equipment racks and subassemblies. Make field
connections of all audio, video and control wiring including microphone, line level,
loudspeaker, video, SDI signal, Ethernet and control system circuits to equipment, equipment
racks and connection panels. Continuously supervise the installation and connections of
cable and equipment.
1.3
A.
SUBMITTALS
Shop Drawings and Product Data:
1.
Within 45 days of contract award, the following is required for approval, prior to
ordering product, fabrication and installation. Provide three (3) copies unless otherwise
specified. Submit complete and at one time. Isolated items will not be considered for
approval, except by prior authorization. Rejected items and items requiring correction
must be resubmitted at one time, except by prior authorization.
2.
The diagrams and details included with these specifications, modified to reflect the
stated requirements and to reflect the details of the system as awarded, and including all
additional required information, may be used in preparing shop drawings. Drawings
that are submitted without the necessary modifications will be rejected.
3.
All drawings shall be drawn on a computer-aided drafting (CAD) system.
a.
Bill of Materials and Catalog Data Sheets of all manufactured items. At the end
of the Bill of Materials include Catalog Data Sheets (“cut” sheets) for all product
arranged in the order listed in the specifications and in the Bill of Materials.
Submit in bound form using a 3-ring, GBC or similar binding, and including a
cover page identifying the project and submittal. Organize the Bill of Materials
with the information presented in the order that it appears in this specification, in
6 columns from left to right:
1)
Paragraph number as it appears in this specification.
2)
Paragraph title as it appears in this specification.
3)
Manufacturer.
4)
Model number.
5)
Quantity.
6)
Comments (if any are needed).
b.
Block diagrams indicating proposed connections of all equipment and indicating
equipment types and model numbers.
c.
Equipment/control room layout(s), and equipment rack and cabinet details.
d.
Video camera, video monitor mounting arrangements.
e.
Shop drawings of any unit, such as control panels, switch panels to be fabricated
or modified.
2
27
January 19, 2013
f.
g.
TV Studio Communication Equipment
Richard Stockton College of New Jersey
Submittals as required by specifications.
Others as required by the college or Consultant.
B.
Samples:
1.
Finish for control panels, racks, cabinets, and loudspeaker grilles.
2.
Mechanical connectors for use in wiring.
C.
Test Reports: Upon completion of SYSTEM PERFORMANCE TESTS AND
ADJUSTMENTS specified in SECTION 2.1 G, submit for approval in writing test results
including numerical values for all measurements. Also submit written certification that the
installation conforms to specifications, is complete and operable, and is ready for FINAL
ADJUSTMENTS AND ACCEPTANCE TESTS specified in SECTION 2.1H. Provide three
(3) copies unless otherwise specified.
D.
Operation and Maintenance Data
1.
At time of FINAL ADJUSTMENTS AND ACCEPTANCE TESTS specified in
SECTION 2.1 H provide draft copies of all specified diagrams, schedules and manuals
for inspection during demonstration and acceptance testing. Submit final copies
thereafter. All drawings shall be drawn on a computer-aided drafting (CAD) system.
For Contractor-prepared drawings, schedules and instructions, provide three (3) draft
copies, one (1) final copy for specified mounting, and two (2) final copies for inclusion
in specified Complete Instruction and Maintenance Manual, unless a different quantity
is otherwise specified.
2.
All final printed copies of As-Built drawings shall be delivered on Mylar film.
3.
Provide electronic copies (AutoCAD format) of all As-Built drawings.
4.
Functional Diagrams: Simplified single line block diagram showing interconnection of
all major equipment components and functional relationships. Illustrate all receptacles,
patch panel jacks, attenuators, transformers, switches, and loudspeakers. Key each
patch panel jack to the patch bay by row and jack number. Diagram shall not illustrate
terminal or interconnection cable number designations. The Functional Diagram
included with these specifications, modified to exclude details, transformer tap
designations, etc., and to provide the information described above and any as-built
changes, is suitable for this purpose. Complete on a single sheet of minimum size 24"
by 36". Mount one photographic, wash-off Mylar or rag paper photocopy print of each
system behind acrylic at locations to be determined.
5.
As-Built Diagrams:
a.
The intent of the diagrams is to provide sufficiently clear and complete
information that a technician of average skill may efficiently troubleshoot and
service the system, even if unfamiliar with the installation.
b.
Provide drawings showing all terminal blocks, connectors, relays, switches,
routers, interfaces, transformers, attenuators, equipment components, and wires.
Label all devices with manufacturer, model number, and reference number (e.g.
"SW 15", "TB 6"); reference numbers shall be consistent across all drawings with
no repetitions. As a minimum, provide an expanded version of the functional
diagrams with cables fanned out at termination points and all labeling as specified
3
28
January 19, 2013
6.
7.
8.
9.
TV Studio Communication Equipment
Richard Stockton College of New Jersey
above; provide additional drawings where system complexity does not permit
complete information to be shown legibly on an individual sheet no larger than
the project sheet size. Provide labels for cables continued onto another drawing,
indicating termination device, terminal numbers, and drawing sheet on which the
termination is shown.
c.
Provide layout drawings of panels and other custom assemblies containing
routers, interfaces, switches, relays, terminal blocks, receptacles, etc., using
reference numbers to identify physical locations of devices or label devices with
reference numbers in a location visible while viewing cable terminations. On
wiring diagrams, label all conductors within cables for insulation color or other
identifier. Label connectors, barrier strips, switches, relay sockets, etc., for
terminal number. If device does not provide terminal designations, provide key
diagram for reference.
Complete Instruction and Maintenance Manual: Prepare in the form of an instructional
manual for use by the college's personnel. Provide one (1) draft copy and two (2) final
copies unless otherwise specified.
Format:
a.
Size: 8-1/2" x 11", 20 lb. minimum weight white paper for typed pages, either
manufacturer's printed data, or neatly typewritten.
b.
Drawings: Provide reinforced punched binder tab, bind in with text. Fold larger
drawings to size of text pages. Clear plastic "binding tape" (not "Scotch" tape)
applied to edge of sheet and then punched is acceptable.
c.
Single-sheet product literature and contractor-prepared pages: Provide reinforced
punched binder tab. Clear plastic "binding tape" (not "Scotch" tape) applied to
edge of page and then punched is acceptable.
d.
Provide indexed tabs and flyleaf for each separate product, or each piece of
operating equipment. Include typed description of product, and major component
parts of equipment.
e.
Cover: Identify each volume with typed or printed title "OPERATING AND
MAINTENANCE INSTRUCTIONS".
Binders:
a.
Commercial quality three-ring binders with durable and cleanable plastic covers,
1" minimum, 2" maximum ring size.
b.
When multiple binders are used, collate the data into related consistent groupings.
Content of Manuals:
a.
Neatly typewritten table of contents for each volume, arranged in systematic
order. Identify each product by product name and other identifying symbols as
set forth in Contract Documents.
b.
Contractor, name of responsible principal, address and telephone number.
c.
Certificate of Warranty for the system as a whole as well as copies of the
manufacturer’s warranty for each equipment item.
d.
Service Contract. Include a preliminary schedule for the specified semi-annual
site visits.
e.
Complete as-built diagrams for system.
f.
Functional Diagram.
g.
Building Plan.
4
29
January 19, 2013
h.
i.
1.4
TV Studio Communication Equipment
Richard Stockton College of New Jersey
Original copies, high-quality laser printer printouts of PDF files, or high-quality
photocopies of manufacturers' installation, operation, and service manuals,
including schematic diagrams for each equipment item.
Shop drawings of all custom-fabricated items.
JOB CONDITIONS
A.
Sequencing and Scheduling:
1.
Determine and coordinate phasing and scheduling, facility access and staging area
requirements with college. Minor modifications of locations required to effect such
coordination will be made at no cost to the college.
2.
Project Manager to be available for weekly progress meetings for the duration of the
project. Meetings shall be scheduled by the college.
B.
Refuse: Remove all refuse from the job site to the satisfaction of the college.
1.5
WARRANTY
A.
Warrant all equipment to be free of faulty workmanship and defects and from damage due to
contamination by construction dust and debris for a minimum period of one year from date of
final acceptance.
B.
Warrant all repairs to "existing" equipment for a period of 90 days.
C.
Emergency service: Within 24 hours of notification, restore the system to operation, replacing
defective materials and repairing faulty workmanship. Make temporary repairs and provide
loaner equipment at no charge if defective materials cannot be permanently replaced or
repaired within this 24 hour time period.
D.
Paint and exterior finishes, fuses, lamps, projection lamps, and video picture tubes excluded
from above warranties except when damage or failure results from defective materials or
workmanship covered by warranty.
E.
The minimum warranty provisions specified above shall not diminish the terms of individual
equipment manufacturers' warranties.
1.6
SERVICE CONTRACT
A.
Provide a one-year service contract to commence after acceptance of installation without
additional cost. Service to include two semi-annual visits to the site for routine adjustment
and maintenance of all equipment. Provide a preliminary schedule for the semiannual visits.
B.
Towards the end of each year's Service Contract, provide the college with a proposal for
continued service during the next year.
5
30
January 19, 2013
1.7
TV Studio Communication Equipment
Richard Stockton College of New Jersey
TRAINING
A.
The college may assign personnel to participate with the contractor during installation.
Without delaying the work, familiarize the college's personnel with the installation,
equipment, and maintenance.
B.
During tests and adjustments, permit the college's personnel to observe. When feasible
explain the significance of each test.
C.
Provide sufficient training to personnel selected by the college on operation and basic
maintenance of all systems and equipment. Explain operation of control systems, set-up and
operation of individual pieces of equipment and functions of overall systems. Provide a
minimum total of five days of training time, to be scheduled at the request of the college.
D.
Separate from the total bid price, provide an hourly cost for additional training.
1.8
LABELS & MISCELLANEOUS
A.
Except where otherwise specified, label as shown on drawings and as specified each item of
rack-mounted equipment, all switches, controls, and receptacles.
1.
Switch and Control Panels: Constructed of engraved and filled anodized aluminum
plates. Minimum 1/8" plate thickness. Dry transfer or other types of adhesive labels
not acceptable.
2.
Rack-Mounted Equipment: Labels constructed of engraved and filled plastic laminate
engraving stock. Designate function and input and output line(s) or loudspeaker(s)
served by labeled equipment. Key all designations to system functional and patch
panel diagrams. Where possible, mount labels on blank panel directly above
corresponding component. For modular equipment, provide label on inside of
mainframe door identifying type of module for each slot (unless there is only one type)
and gain setting as established at final checkout.
B.
Identify all wires and cables at every termination and connection point with the specified
cable markers. The contractor is strongly encouraged to use a numbering scheme that
identifies all cables terminating at patch panel jacks with the patch bay row and jack
designation; use A, B, and C suffixes to distinguish multiple cables terminating at the same
jack.
C.
Identify switches, routers, interfaces, relays, terminal blocks, etc., with reference numbers
keyed to the as-built wiring diagrams.
D.
All labels and legends shall be as approved on shop drawings.
E.
Cable Markers:
6
31
January 19, 2013
1.
2.
TV Studio Communication Equipment
Richard Stockton College of New Jersey
High-grade PVC clip-on or permanent-type cable markers with permanent markings, or
printed vinyl tape protected by clear shrink tubing or adhesive wrap.
Acceptable Product:
a.
Electrovert Type C or Z.
b.
Brady B-702 with Alpha FIT-221 series clear tubing.
c.
Thomas & Betts EZCODER.
d.
Approved Equal. (after the award)
EXECUTION
2.1
GENERAL
A.
All types of equipment installed by competent workers in strict accordance with approved
shop drawings and manufacturer's instructions.
B.
All equipment except portable equipment firmly held in place. This shall include equipment
frames, loudspeakers, enclosures, amplifiers, cables, etc. Fastenings and supports adequate
to support their loads with a safety factor of at least three unless otherwise stated.
C.
Take such precautions as necessary to prevent and guard against electro-magnetic and electrostatic hum and to install the equipment so as to provide safety for the operator.
D.
Protect all equipment, including patch panels, connectors, receptacles, racks, and consoles,
from construction dust and debris until final acceptance of the system.
Wiring and Interconnections:
1.
General:
a.
Exercise care in wiring to avoid damage to cables and equipment.
b.
Make all joints and connections with rosin-core solder or approved mechanical
connectors.
c.
All connections to screw-type terminals shall be made using spade lugs. Bare or
tinned wire is not acceptable.
d.
All connections to lug-less compression-type screw terminals shall be made using
bare wire only. Do not tin wire.
e.
All wiring executed in strict adherence to standard broadcast practices. This
includes:
1)
Dress cables in conveniently sized bundles, combed into parallel runs,
either laced or banded with sufficient plastic ties.
2)
For equipment mounted on glides, or otherwise requiring servicing from the
front of the rack incorporate a cable "service loop" of sufficient length to
permit the equipment to be pulled forward from the rack for servicing.
3)
Support cables and bundles with sufficient plastic ties and support bars to
ensure that no strain is placed on any connections or connectors.
7
32
January 19, 2013
TV Studio Communication Equipment
Richard Stockton College of New Jersey
4)
2.
Organize cables and cable bundles behind patch bays to permit easy access
to the patch panels to add or remove cables.
5)
Place cable markers 3"-5" back from video connectors to permit easy
viewing. Do not bind markers into cable bundles.
f.
All audio signal lines carried by twisted-pair cable and switched with two poles
per line unless noted otherwise. Do not tie one side of audio line to other audio
lines.
Grounding:
a.
Ground equipment, racks, and audio line shields to independent audio system
ground ONLY as shown on drawings. If not shown on drawings, ground case of
power strip-lines in equipment racks to the racks and directly to isolated ground
buss in the power panel or to power system ground at the building AC service
entry only.
b.
Ground all conduits ONLY to power system ground. Insulate all conduits and
electrical boxes from sound system, including equipment racks and audio system
ground.
c.
Insulate all conductors in conduit, including shields, from the conduit, back
boxes, and from each other for the entire conduit length.
E.
Equipment Racks:
1.
Install equipment in racks to permit access to all equipment for service. Transformers,
relays, terminal blocks, etc., mounted in rear of racks behind other equipment shall not
prevent access to equipment connections or shall be mounted on hinged panels to
permit access.
2.
Install equipment in racks with ventilating panels as required to provide adequate
ventilation and according to equipment manufacturer's recommendations.
3.
Connect all microphones, DC control, and line level cables to equipment racks via
specified audio terminal blocks. External lines to patch bay terminated directly on
patch bay terminal blocks.
4.
Connect loudspeaker lines with spade lugs if barrier strips are used. Do not buss
commons together. Do not ground.
5.
Provide unused panel space with blank or ventilating panels.
6.
Equip racks not bolted to the floor because of service access with "Anti-tip" bases,
casters and brake.
F.
Exposed Cables:
1.
Line level or mic level lines exposed above countertops (such as those lines serving
mixing consoles, program source equipment, etc.) shall be rubber-jacketed, AWG #20
two conductor with braided shield such as Belden 8412 or equivalent. Plastic or vinyl
jacketed cables are not acceptable.
G.
SYSTEM PERFORMANCE TESTS AND ADJUSTMENTS
1.
Test all equipment to verify conformance with manufacturer’s performance
specifications and with this specification.
8
33
January 19, 2013
TV Studio Communication Equipment
Richard Stockton College of New Jersey
H.
FINAL ADJUSTMENTS AND ACCEPTANCE TESTS
1.
Upon approval of the contractor's test report, and at a time set by the College, assist the
Consultant(s) in performing final system adjustments and acceptance tests. Provide all
labor, material, tools, and measurement equipment necessary for these tests and
adjustments, including the test equipment and material specified, except as otherwise
specified.
2.
The contractor's representatives assisting in performance of these tests shall be
thoroughly familiar with all details of the system, and shall include the field supervisor
in overall charge during the course of the installation work.
3.
Budget 14 working hours for the performance of these tests and adjustments. If final
acceptance is delayed beyond this period because of installation not in accordance with
these specifications, pay for all additional time and expenses of Consultant(s) during
any resultant extension of the acceptance testing period.
I.
Acceptance tests may include speech intelligibility surveys and subjective evaluations by
observers listening at various positions under various operating conditions, using speech,
music, and live or recorded effects material.
J.
Measurement of frequency response, distortion, noise, or other characteristics may be
performed on any item or group of items deemed necessary to determine conformity with
specifications.
K.
Adjustments: Adjust the system as instructed by the Consultant.
END OF SECTION
9
34
EXHIBIT C TV Studio equipment to be integrated with new HDTV system The following equipment can be used as part of the new HDTV studio system. Components should be tested, configured and included in the design plans for the new HDTV system. 1. 2 each, JBL control room speaker monitors 2. 3 each, Teleprompter camera support platform, mounting plates, LCD monitors, reflective glass enclosure 3. 1 each, Analog video distribution amplifier for Teleprompters 4. 1 each, current PC computer for teleprompting system, including VGA to Composite converter and scroll control device. The remaining inventory of studio and control room electronic equipment, power strips, cables and accessories will be removed and stored in the studio space. Richard Stockton College of NJ will evaluate the equipment and provide for its disposition. Any equipment racks, console and camera supports will be removed from the college property by the vendor. 1 35
EXHIBIT C This equipment list is not all inclusive. Vendor design may require additional equipment components. Richard Stockton College of NJ will review and approve any substitutions of equipment submitted as a result of the vendor’s system design. Qty 3 3 6 9 3 3 HD Field TV Production Equipment Description Panasonic AG‐HMC150D HD Camcorder, AGHMC150PJU Panasonic AG‐YUS150H Soft Case w/3" LCD Hood Panasonic 7.2 V 5800MA Battery VWVBG6PPK Sandisk Extreme SDHC class 10 32GB card SDSDX3032G Libec RH25/RT30B/SP‐2B/RC‐30 Tripod System RS250 Dane‐Elec DA‐Combo15‐1 SDHC Memory Reader Qty 3 1 1 1 2 1 1 2 1 1 1 3 3 1 1 2 1 1 1 3 Studio HDTV Equipment Description JVC HD Production Camera GY‐HM790/studio accessory control/lens ROSS 16 Input HDTV Production Switcher CrossOver 16 ROSS HD CG Expression / Studio/No Prime upgrade/operator station BlackStorm Production Server/with operator control station Panasonic 42" LCD for control room Monitoring TH‐42LH20 AJA HD‐SDI to HDMI Converter Bittree Audio/Video Patch Panel Marshall 7” Widescreen Dual LCD Marshall LCD with Waveform Vector Crown Audio XTi 1002 Power Amplifier Soundcraft LX7II 16 channel JBL Speaker Control 5 JBL Speaker Mount Harris Panacea Router 16x16 Harris Tri Level Sync Generator 3900 AJA HD‐SDI to HDMI Converter Hi‐5 Clear‐Com Intercom system, 6 headsets included Studio talkback audio amplifier Furniture and racks Camera Pedestal support system, 50lb capacity 2 36
Drawing E032-34
37
THE RICHARD STOCKTON COLLEGE OF NEW JERSEY
BID DOCUMENT CHECKLIST
A. Failure to submit the following documents is a mandatory cause for the bid to be rejected.
Required with
Submission of Bid
(Owner’s “X”)
Initial Each Item
Submitted with Bid
(Bidder’s Initials)
x
Signature on Page 1 of Request For Proposal
x
A statement of ownership, pursuant to N.J.S.A. 52:25-24-2
x
Acknowledgement of Equal Employment Opportunity Language
x
Employee or Relative Disclosure Requirement
x
Submission of a Non-Collusion Affidavit (form must be Notarized)
x
Public Works Contractor Registration Act P.L.1999.c238
x
Certificate of Registration with the Division of Revenue PL 2001, c.134
x
W-9 Form Request for Taxpayer Identification Number and Certification
x
A bid guarantee as required by N.J.S.A. 18A:64-67
A surety company certificate, pursuant to N.J.S.A. 18A:64-68
x
If Applicable, bidder’s acknowledgement of receipt of any notice(s) or
revision(s) or addenda to an advertisement, specifications or bid document(s)
Affidavit of Outreach
x
Public Law 2005, Chapter 51 (formerly Executive Order 134) and Executive
Order 117 (2008)
x
Public Law 2005, Chapter 92 (formerly Executive Order 129)
Source Disclosure Certification Form
B. Signature: The undersigned hereby acknowledges and has submitted the above listed requirements.
Name of Bidder:
Authorized Representative Signature:
Print Name & Title:
Date:
38
STATEMENT OF OWNERSHIP, PURSUANT TO N.J.S.A. 52:25‐24‐2 PLEASE FOLLOW THE LINK BELOW FOR AN OWNERSHIP DISCLOSURE FORM. PLEASE COMPLETE AND SUBMIT IT ALONG WITH THE OTHER REQUIRED DOCUMENTS FOR THE THIS REQUEST FOR PROPOSAL. http://www.state.nj.us/treasury/purchase/forms/StandardRFPForms.pdf 39
(REVISED 4/10)
MANDATORY EQUAL EMPLOYMENT OPPORTUNITY LANGUAGE
N.J.S.A. 10:5-31 et seq. (P.L. 1975, C. 127)
N.J.A.C. 17:27
GOODS, PROFESSIONAL SERVICE AND GENERAL SERVICE CONTRACTS
During the performance of this contract, the contractor agrees as follows:
The contractor or subcontractor, where applicable, will not discriminate
against any employee or applicant for employment because of age, race, creed,
color, national origin, ancestry, marital status, affectional or sexual
orientation, gender identity or expression, disability, nationality or sex.
Except with respect to affectional or sexual orientation and gender identity
or expression, the contractor will ensure that equal employment opportunity is
afforded to such applicants in recruitment and employment, and that employees
are treated during employment, without regard to their age, race, creed,
color, national origin, ancestry, marital status, affectional or sexual
orientation, gender identity or expression, disability, nationality or sex.
Such equal employment opportunity shall include, but not be limited to the
following: employment, upgrading, demotion, or transfer; recruitment or
recruitment advertising; layoff or termination; rates of pay or other forms of
compensation; and selection for training, including apprenticeship. The
contractor agrees to post in conspicuous places, available to employees and
applicants for employment, notices to be provided by the Public Agency
Compliance Officer setting forth provisions of this nondiscrimination clause.
The contractor or subcontractor, where applicable will, in all
solicitations or advertisements for employees placed by or on behalf of the
contractor, state that all qualified applicants will receive consideration for
employment without regard to age, race, creed, color, national origin,
ancestry, marital status, affectional or sexual orientation, gender identity
or expression, disability, nationality or sex.
The contractor or subcontractor will send to each labor union, with which
it has a collective bargaining agreement, a notice, to be provided by the
agency contracting officer, advising the labor union of the contractor's
commitments under this chapter and shall post copies of the notice in
conspicuous places available to employees and applicants for employment.
The contractor or subcontractor, where applicable, agrees to comply with any
regulations promulgated by the Treasurer pursuant to N.J.S.A. 10:5-31 et seq.,
as amended and supplemented from time to time and the Americans with
Disabilities Act.
The contractor or subcontractor agrees to make good faith efforts to meet
targeted county employment goals established in accordance with N.J.A.C.
l7:27-5.2.
40
The contractor or subcontractor agrees to inform in writing its
appropriate recruitment agencies including, but not limited to, employment
agencies, placement bureaus, colleges, universities, and labor unions, that it
does not discriminate on the basis of age, race, creed, color, national
origin, ancestry, marital status, affectional or sexual orientation, gender
identity or expression, disability, nationality or sex, and that it will
discontinue the use of any recruitment agency which engages in direct or
indirect discriminatory practices.
The contractor or subcontractor agrees to revise any of its testing
procedures, if necessary, to assure that all personnel testing conforms with
the principles of job-related testing, as established by the statutes and
court decisions of the State of New Jersey and as established by applicable
Federal law and applicable Federal court decisions.
In conforming with the targeted employment goals, the contractor or
subcontractor agrees to review all procedures relating to transfer, upgrading,
downgrading and layoff to ensure that all such actions are taken without
regard to age, race, creed, color, national origin, ancestry, marital status,
affectional or sexual orientation, gender identity or expression, disability,
nationality or sex, consistent with the statutes and court decisions of the
State of New Jersey, and applicable Federal law and applicable Federal court
decisions.
The contractor shall submit to the public agency, after notification of
award but prior to execution of a goods and services contract, one of the
following three documents:
Letter of Federal Affirmative Action Plan Approval
Certificate of Employee Information Report
Employee Information Report Form AA302 (electronically provided by the
Division and distributed to the public agency through the Division’s website
at www.state.nj.us/treasury/contract_compliance)
The contractor and its subcontractors shall furnish such reports or other
documents to the Division of Public Contracts Equal Employment Opportunity
Compliance as may be requested by the office from time to time in order to
carry out the purposes of these regulations, and public agencies shall furnish
such information as may be requested by the Division of Public Contracts Equal
Employment Opportunity Compliance for conducting a compliance investigation
pursuant to Subchapter 10 of the Administrative Code at N.J.A.C. 17:27.
41
AFFIRMATIVE ACTION COMPLIANCE NOTICE
N.J.S.A. 10:5-31 and N.J.A.C. 17:27
GOODS AND SERVICES CONTRACTS
(INCLUDING PROFESSIONAL SERVICES)
This form is a summary of the successful bidder’s requirement to comply with the requirements of N.J.S.A. 10:531 and N.J.A.C. 17:27-1 et seq.
The successful bidder shall submit to the public agency, after notification of award but prior to execution of this
contract, one of the following three documents as forms of evidence:
(a) A photocopy of a valid letter that the contractor is operating under an existing
Federally approved or sanctioned affirmative action program (good for one year from the
date of the letter);
OR
(b) A photocopy of a Certificate of Employee Information Report approval, issued in
accordance with N.J.A.C. 17:27-4;
OR
(c) A photocopy of an Employee Information Report (Form AA302) provided by the
Division and distributed to the public agency to be completed by the contractor in
accordance with N.J.A.C. 17:27-4.
The successful vendor may obtain the Affirmative Action Employee Information Report (AA302) from the
contracting unit during normal business hours.
The successful vendor(s) must submit the copies of the AA302 Report to the Division of Contract Compliance and
Equal Employment Opportunity in Public Contracts (Division). The Public Agency copy is submitted to the public
agency, and the vendor copy is retained by the vendor.
The undersigned vendor certifies that he/she is aware of the commitment to comply with the requirements of
N.J.S.A. 10:5-31 and N.J.A.C. 17:27.1 et seq. and agrees to furnish the required forms of evidence.
The undersigned vendor further understands that his/her bid shall be rejected as non-responsive if said contractor
fails to comply with the requirements of N.J.S.A. 10:5-31 and N.J.A.C. 17:27-1 et seq.
COMPANY: ____________________________
SIGNATURE: ____________________________
PRINT NAME:_____________________________
TITLE: _______________________________
DATE: __________________
42
PURCHASING OFFICE
EMPLOYEE OR RELATIVE DISCLOSURE REQUIREMENT
This form is to be completed by all bidders seeking the award of any contract. No bidder shall be awarded any contract nor shall any
agreement be entered into for the performance of any work or the furnishing of any materials or supplies, the cost of which is to be
paid with or out or any public funds by Richard Stockton College of New Jersey unless prior to the receipt of the bid or accompanying
the bid, the bidder has submitted a statement setting forth the information solicited below.
1.
State if you or your employee (if known) are currently employed at Richard Stockton College of New Jersey. YES ____ NO ____
If so, please indicate name and position held at Richard Stockton College of New Jersey.
2.
State if any shareholder who owns 10 % or more of your stock, if a corporation or partner who holds 10% or more of an interest,
if a partnership, is currently employed at Richard Stockton College of New Jersey. YES ____ NO ____
If so, please indicate name and position held at Richard Stockton College of New Jersey.
3.
State if you, or any stockholder, who owns 10% or more of your stock, if a corporation, or any partner who owns 10% or more of
an interest, if a partnership, as the case may be, has any relatives employed at the College. YES ____ NO ____
4.
State if you or your employee (if known) is currently a student at Richard Stockton College of New Jersey. YES ____ NO ____
BY:
(Nam
e of Contractor)
(A
Signature of Authorized Representative:
Type of Print Name:
Title:
Witnessed by:
Date:
43
-
ddress)
NON-COLLUSION AFFIDAVIT
I,
of
of
and the State of
according to law on my oath, depose and say that:
, in the County
of full age, being duly sworn
I am
of the Firm of
The Bidder making the Proposal for the Project, and that I executed the Proposal with the
full authority to do so, that the Bidder has not directly or indirectly entered into any
agreement, participated in any collusion or otherwise taken any action in restraint of free,
competitive bidding in connection with the Project, and that all statements contained in
the Proposal and in this Affidavit are true and correct, and made with full knowledge that
The Richard Stockton College of New Jersey relies upon the truth on the statements
contained in the Proposal and in the statements contained in this Affidavit in awarding
the Contract for the Project.
I warrant that no requirement or commitment was made in reference to and persons, or
elected official and that no undisclosed benefits of any kind were promised to anyone
connected with the project.
I further warrant that no person or selling agent has been employed or retained to solicit
or secure such contract upon an agreement or understanding for a commission,
percentage, brokerage or contingent fee, except bonafide employees or a bonafide
established commercial or selling agencies maintained by
(N.J.S.A. 52:34-15)
(Name of Contractor)
I also understand that the above disqualification does not apply to any vendor who
cooperates with the prosecution and gives supporting testimony on behalf of the
prosecution in the course of a judicial inquiry.
Subscribed and Sworn to
day
Before me this
of
20
Notary Public of
My Commission expires
.
(Signature of Affiant)
(Print
or Type Name of Affiant)
44
W-9
Request for Taxpayer
Identification Number and Certification
Form
(Rev. January 2011)
Department of the Treasury
Internal Revenue Service
Give Form to the
requester. Do not
send to the IRS.
Print or type
See Specific Instructions on page 2.
Name (as shown on your income tax return)
Business name/disregarded entity name, if different from above
Check appropriate box for federal tax
classification (required):
Individual/sole proprietor
C Corporation
S Corporation
Partnership
Trust/estate
Exempt payee
Limited liability company. Enter the tax classification (C=C corporation, S=S corporation, P=partnership) a
Other (see instructions) a
Address (number, street, and apt. or suite no.)
Requester’s name and address (optional)
City, state, and ZIP code
List account number(s) here (optional)
Part I
Taxpayer Identification Number (TIN)
Enter your TIN in the appropriate box. The TIN provided must match the name given on the “Name” line
to avoid backup withholding. For individuals, this is your social security number (SSN). However, for a
resident alien, sole proprietor, or disregarded entity, see the Part I instructions on page 3. For other
entities, it is your employer identification number (EIN). If you do not have a number, see How to get a
TIN on page 3.
Social security number
Note. If the account is in more than one name, see the chart on page 4 for guidelines on whose
number to enter.
Employer identification number
–
–
–
Part II
Certification
Under penalties of perjury, I certify that:
1. The number shown on this form is my correct taxpayer identification number (or I am waiting for a number to be issued to me), and
2. I am not subject to backup withholding because: (a) I am exempt from backup withholding, or (b) I have not been notified by the Internal Revenue
Service (IRS) that I am subject to backup withholding as a result of a failure to report all interest or dividends, or (c) the IRS has notified me that I am
no longer subject to backup withholding, and
3. I am a U.S. citizen or other U.S. person (defined below).
Certification instructions. You must cross out item 2 above if you have been notified by the IRS that you are currently subject to backup withholding
because you have failed to report all interest and dividends on your tax return. For real estate transactions, item 2 does not apply. For mortgage
interest paid, acquisition or abandonment of secured property, cancellation of debt, contributions to an individual retirement arrangement (IRA), and
generally, payments other than interest and dividends, you are not required to sign the certification, but you must provide your correct TIN. See the
instructions on page 4.
Sign
Here
Signature of
U.S. person a
Date a
General Instructions
Note. If a requester gives you a form other than Form W-9 to request
your TIN, you must use the requester’s form if it is substantially similar
to this Form W-9.
Definition of a U.S. person. For federal tax purposes, you are
considered a U.S. person if you are:
• An individual who is a U.S. citizen or U.S. resident alien,
• A partnership, corporation, company, or association created or
organized in the United States or under the laws of the United States,
• An estate (other than a foreign estate), or
• A domestic trust (as defined in Regulations section 301.7701-7).
Special rules for partnerships. Partnerships that conduct a trade or
business in the United States are generally required to pay a withholding
tax on any foreign partners’ share of income from such business.
Further, in certain cases where a Form W-9 has not been received, a
partnership is required to presume that a partner is a foreign person,
and pay the withholding tax. Therefore, if you are a U.S. person that is a
partner in a partnership conducting a trade or business in the United
States, provide Form W-9 to the partnership to establish your U.S.
status and avoid withholding on your share of partnership income.
Section references are to the Internal Revenue Code unless otherwise
noted.
Purpose of Form
A person who is required to file an information return with the IRS must
obtain your correct taxpayer identification number (TIN) to report, for
example, income paid to you, real estate transactions, mortgage interest
you paid, acquisition or abandonment of secured property, cancellation
of debt, or contributions you made to an IRA.
Use Form W-9 only if you are a U.S. person (including a resident
alien), to provide your correct TIN to the person requesting it (the
requester) and, when applicable, to:
1. Certify that the TIN you are giving is correct (or you are waiting for a
number to be issued),
2. Certify that you are not subject to backup withholding, or
3. Claim exemption from backup withholding if you are a U.S. exempt
payee. If applicable, you are also certifying that as a U.S. person, your
allocable share of any partnership income from a U.S. trade or business
is not subject to the withholding tax on foreign partners’ share of
effectively connected income.
Cat. No. 10231X
45
Form W-9 (Rev. 1-2011)
Public Law 2005, Chapter 51
(formerly Executive Order 134) and Executive
Order 117 (2008)
INFORMATION AND INSTRUCTIONS
For Completing The “Two- Year Vendor Certification and Disclosure of Political
Contributions” Forms
Background Information
On September 22, 2004, then-Governor James E. McGreevey issued Executive Order 134, the purpose of which was to
insulate the negotiation and award of State contracts from political contributions that posed a risk of improper influence,
purchase of access or the appearance thereof. To this end, Executive Order 134 prohibited State departments, agencies
and authorities from entering into contracts exceeding $17,500 with individuals or entities that made certain political
contributions. Executive Order 134 was superseded by Public Law 2005, c. 51, signed into law on March 22, 2005
(“Chapter 51”).
On September 24, 2008, Governor Jon S. Corzine issued Executive Order No. 117 (“E.O. 117”), which is designed to
enhance New Jersey’s efforts to protect the integrity of procurement decisions and increase the public’s confidence in
government. The Executive Order builds upon the provisions of Chapter 51.
Two-Year Certification Process
Upon approval by the State, the Certification and Disclosure of Political Contributions form (CH51.1R1/21/2009) is valid
for a two (2) year period. Thus, if a vendor receives approval on Jan 1, 2009, the certification expiration date would be
Dec 31, 2011. Any change in the vendor’s ownership status and/or political contributions during the two-year period will
require the submission of new Chapter 51/EO117 forms to the State Review Unit. Please note that it is the vendor’s
responsibility to file new forms with the State should these changes occur.
Prior to the awarding of a contract, the agency should first send an e-mail to [email protected] to verify the
certification status of the vendor. If the response is that the vendor is NOT within an approved two-year period, then
forms must be obtained from the vendor and forwarded for review. If the response is that the vendor is within an
approved two-year period, then the response so stating should be placed with the bid/contract documentation for the
subject project.
Instructions for Completing the Forms
NOTE: Please refer to the next section, “Useful Definitions for Purposes of Ch. 51 and E.O. 117,” for guidance when
completing the forms.
Part 1: VENDOR INFORMATION
Business Name – Enter the full name of the Vendor, including trade name if applicable.
Business Type -- Select the vendor’s business organization from the list provided.
Address, City, State, Zip and Phone Number -- Enter the vendor’s street address, city, state, zip code and telephone
number.
Vendor Email – Enter the vendor’s primary email address.
Vendor FEIN – Please enter the vendor’s Federal Employment Identification Number.
DPP c51 - C&D, Rev. 11-17-2008
Page 1 of 4
46
Public Law 2005, Chapter 51
(formerly Executive Order 134) and Executive
Order 117 (2008)
INFORMATION AND INSTRUCTIONS
For Completing The “Two- Year Vendor Certification and Disclosure of Political
Contributions” Forms
Part 2: PUBLIC LAW 2005, Chapter 51 / EXECUTIVE ORDER 117 (2008) DUAL
CERTIFICATION
Read the following statements and verify that from the period beginning on or after October 15, 2004, no contributions as
set forth at subsections 1(a)-(c) have been made by either the vendor or any individual whose contributions are
attributable to the vendor pursuant to Executive Order 117 (2008).
NOTE: Contributions made prior to November 15, 2008 are applicable to Chapter 51 only.
Part 3: DISCLOSURE OF CONTRIBUTIONS MADE
Check the box at top of page 2 if no reportable contributions have been made by the vendor. If the
vendor has no contributions to report, this box must be checked.
Name of Recipient Entity – Enter the full name of the recipient entity.
Address of Recipient Entity – Enter the recipient entity’s street address.
Date of Contribution – Indicate the date of the contribution.
Amount of Contribution – Enter the amount of the reportable contribution.
Type of Contribution – Select the type of contribution from the list provided.
Contributor Name – Enter the full name of the contributor.
Relationship of Contributor to the Vendor -- Indicate relationship of the contributor to the vendor, e.g. officer or partner
of the company, spouse of officer or partner, resident child of officer or partner, parent company of the vendor, subsidiary
of the vendor, etc.
NOTE: If form is being completed electronically, click “Add a Contribution” to enter additional contributions. Otherwise,
please attach additional pages as necessary.
Part 4: CERTIFICATION
Check box A if the person completing the certification and disclosure is doing so on behalf of the vendor and all
individuals and/or entities whose contributions are attributable to the vendor.
Check box B if the person completing the certification and disclosure is doing so on behalf of the vendor only.
Check box C if the person completing the certification and disclosure is doing so on behalf of an individual and/or entity
whose contributions are attributable to the vendor.
Enter the full name of the person authorized to complete the certification and disclosure, the person’s title or position, date
and telephone number.
DPP c51 - C&D, Rev. 11-17-2008
Page 2 of 4
47
Public Law 2005, Chapter 51
(formerly Executive Order 134) and Executive
Order 117 (2008)
INFORMATION AND INSTRUCTIONS
For Completing The “Two- Year Vendor Certification and Disclosure of Political
Contributions” Forms
USEFUL DEFINITIONS FOR THE PURPOSES OF Ch. 51 and E.O. 117
•
“Vendor” means the contracting entity.
•
“Business Entity” means any natural or legal person, business corporation, professional services corporation,
limited liability company, partnership, limited partnership, business trust, association or any other legal
commercial entity organized under the laws of New Jersey or any other state or foreign jurisdiction. The definition
also includes (i) if a business entity is a for-profit corporation, any officer of the corporation and any other person
or business entity that owns or controls 10% or more of the stock of the corporation; (ii) if a business entity is a
professional corporation, any shareholder or officer; (iii) if a business entity is a general partnership, limited
partnership or limited liability partnership, any partner; (iv) if a business entity is a sole proprietorship, the
proprietor; (v) if the business entity is any other form of entity organized under the laws of New Jersey or any
other state or foreign jurisdiction, any principal, officer or partner thereof; (vi) any subsidiaries directly or indirectly
controlled by the business entity; (vii) any political organization organized under 26 U.S.C.A. § 527 that is directly
or indirectly controlled by the business entity, other than a candidate committee, election fund, or political party
committee; and (viii) with respect to an individual who is included within the definition of “business entity,” that
1
individual’s spouse or civil union partner and any child residing with that person.
•
“Officer” means a president, vice-president with senior management responsibility, secretary, treasurer, chief
executive officer, or chief financial officer of a corporation or any person routinely performing such functions for a
corporation. Please note that officers of non-profit entities are excluded from this definition.
•
“Partner” means one of two or more natural persons or other entities, including a corporation, who or which are
joint owners of and carry on a business for profit, and which business is organized under the laws of this State or
any other state or foreign jurisdiction, as a general partnership, limited partnership, limited liability partnership,
limited liability company, limited partnership association, or other such form of business organization.
•
“Reportable Contributions” are those contributions, including in-kind contributions, in excess of $300.00 in the
aggregate per election made to or received by a candidate committee, joint candidates committee, or political
committee; or per calendar year made to or received by a political party committee, legislative leadership
committee, or continuing political committee.
•
“In-kind Contribution” means a contribution of goods or services received by a candidate committee, joint
candidates committee, political committee, continuing political committee, political party committee, or legislative
leadership committee, which contribution is paid for by a person or entity other than the recipient committee, but
does not include services provided without compensation by an individual volunteering a part of or all of his or her
time on behalf of a candidate or committee.
•
“Continuing Political Committee” includes any group of two or more persons acting jointly, or any corporation,
partnership, or any other incorporated or unincorporated association, including a political club, political action
committee, civic association or other organization, which in any calendar year contributes or expects to contribute
at least $4,300 to aid or promote the candidacy of an individual, or the candidacies of individuals, for elective
public office, or the passage or defeat of a public questions, and which may be expected to make contributions
toward such aid or promotion or passage or defeat during a subsequent election, provided that the group,
corporation, partnership, association or other organization has been determined by the Commission to be a
continuing political committee in accordance with N.J.S.A. 19:44A-8(b).
1
Contributions made by a spouse, civil union partner or resident child to a candidate for whom the
contributor is eligible to vote or to a political party committee within whose jurisdiction the contributor
resides are permitted.
DPP c51 - C&D, Rev. 11-17-2008
Page 3 of 4
48
Public Law 2005, Chapter 51
(formerly Executive Order 134) and Executive
Order 117 (2008)
INFORMATION AND INSTRUCTIONS
For Completing The “Two- Year Vendor Certification and Disclosure of Political
Contributions” Forms
•
“Candidate Committee” means a committee established by a candidate pursuant to N.J.S.A. 19:44A-9(a), for
the purpose of receiving contributions and making expenditures.
•
“State Political Party Committee” means a committee organized pursuant to N.J.S.A. 19:5-4.
•
“County Political Party Committee” means a committee organized pursuant to N.J.S.A. 19:5-3.
•
“Municipal Political Party Committee” means a committee organized pursuant to N.J.S.A. 19:5-2.
•
“Legislative Leadership Committee” means a committee established, authorized to be established, or
designated by the President of the Senate, the Minority Leader of the Senate, the Speaker of the General
Assembly, or the Minority Leader of the General Assembly pursuant to N.J.S.A. 19:44A-10.1 for the purpose of
receiving contributions and making expenditures.
•
“Political Party Committee” means:
1. The State committee of a political party, as organized pursuant to N.J.S.A. 19:5-4;
2. Any county committee of a political party, as organized pursuant to N.J.S.A. 19:5-3; or
3. Any municipal committee of a political party, as organized pursuant to N.J.S.A. 19:5-2.
Agency Submission of Forms
The agency should submit the completed and signed Two-Year Vendor Certification and Disclosure forms, together with a
completed Ownership Disclosure form, either electronically to [email protected] or regular mail at Chapter 51
th
Review Unit, P.O. Box 039, 33 West State Street, 9 Floor, Trenton, NJ 08625. Original forms should remain with the
Agency and copies should be sent to the Chapter 51 Review Unit.
Questions & Answers
Questions regarding the interpretation or application of Public Law 2005, Chapter 51 (N.J.S.A. 19:44A-20.13) or Executive
Order 117 (2008) may be submitted electronically through the Division of Purchase and Property website at
http://www.state.nj.us/treasury/purchase/execorder134.htm. Responses to previous questions are posted on the website,
as well as additional reference materials and forms.
NOTE: The Chapter 51 Q&A on the website DOES NOT address the expanded pay-to-play requirements imposed by
Executive Order 117. The Chapter 51 Q&A are only applicable to contributions made prior to November 15, 2008. There
is a separate, combined Chapter 51/E.O. 117 Q&A section dealing specifically with issues pertaining to contributions
made after November 15, 2008, available at http://www.state.nj.us/treasury/purchase/execorder134.htm#state.
DPP c51 - C&D, Rev. 11-17-2008
Page 4 of 4
49
State of New Jersey
Division of Purchase and Property
Two-Year Chapter 51 / Executive Order 117 Vendor Certification and
Disclosure of Political Contributions
For AGENCY USE ONLY
General Information
Solicitation, RFP or Contract No.
Award Amount
Description of Services
Agency Contact Information
Agency
Contact Person
Phone Number
Agency Email
Part 1: Vendor Information
Full Legal Business Name
(Including trade name if applicable)
Business Type
Corporation
Limited Partnership
Limited Liability Company
Sole Proprietorship
Address 1
City
Professional Corporation
General Partnership
Limited Liability Partnership
Address 2
Zip
State
Vendor Email
Phone
Vendor FEIN
Part 2: Public Law 2005, Chapter 51/ Executive Order 117 (2008) Certification
I hereby certify as follows:
1.
On or after October 15, 2004, neither the below-named entity nor any individual whose contributions are attributable to
the entity pursuant to Executive Order 117 (2008) has solicited or made any contribution of money, pledge of contribution,
including in-kind contributions, company or organization contributions, as set forth below that would bar the award of a
contract to the vendor, pursuant to the terms of Executive Order 117 (2008).
a) Within the preceding 18 months, the below-named person or organization has not made a contribution to:
(i)
Any candidate committee and/or election fund of any candidate for or holder of the public office of Governor
or Lieutenant Governor;
(ii) Any State, county, municipal political party committee; OR
(iii) Any legislative leadership committee.
b) During the term of office of the current Governor(s), the below-named person or organization has not made a
contribution to
(i) Any candidate, committee and/or election fund of the Governor or Lieutenant Governor; OR
(ii) Any State, county or municipal political party committee nominating such Governor in the election preceding
the commencement of said Governor's term.
c) Within the 18 months immediately prior to the first day of the term of office of the Governor(s), the below-named
person or organization has not made a contribution to
(i) Any candidate, committee and/or election fund of the Governor or Lieutenant Governor; OR
Any State, county, municipal political party committee of the political party nominating the successful gubernatorial
candidate(s) in the last gubernatorial election.
PLEASE NOTE: Prior to November 15, 2008, the only disqualifying contributions include those made by the vendor or a principal owning
or controlling more than 10 percent of the profits or assets of a business entity (or 10 percent of the stock in the case of a business entity
that is a corporation for profit) to any candidate committee and/or election fund of the Governor or to any state or county political party
within the preceding18 months, during the term of office of the current Governor or within the 18 months immediately prior to the first day of
the term of Office of Governor.
CH51.1 R1/21/2009
Page 1 of 3
50
Part 3: Disclosure of Contributions Made
Check this box if no reportable contributions have been made by the above-named business entity
or individual.
Name of Recipient
Address of Recipient
Date of Contribution
Amount of Contribution
Type of Contribution (i.e. currency, check, loan, in-kind
Contributor Name
Relationship of Contributor to the Vendor
Contributor Address
City
State
Zip
If this form is not being completed electronically, please attach pages for additional contributions
as necessary. Otherwise click "Add a Contribution" to enter additional contributions.
CH51.1 R1/21/2009
Page 2 of 3
51
Part 4: Certification
I have read the instructions accompanying this form prior to completing this certification on behalf of the above-named business entity.
I certify that, to the best of my knowledge and belief, the foregoing statements by me are true. I am aware that if any of the statements
are willfully false, I am subject to punishment.
I understand that this certification will be in effect for two (2) years from the date of approval, provided the ownership status
does not change and/or additional contributions are not made. If there are any changes in the ownership of the entity or additional
contributions are made, a new full set of documents are required to be completed and submitted. By submitting this Certification and
Disclosure, the person or entity named herein acknowledges this continuing reporting responsibility and certifies that it will adhere to it.
(CHECK ONE BOX A, B or C)
(A)
I am certifying on behalf of the above-named business entity and all individuals and/or entities whose contributions are
attributable to the entity pursuant to Executive Order 117 (2008).
(B)
I am certifying on behalf of the above-named business entity only.
(C)
I am certifying on behalf of an individual and/or entity whose contributions are attributable to the vendor.
Signed Name
Print Name
Phone Number
Date
Title/Position
Agency Submission of Forms
The agency should submit the completed and signed Two-Year Vendor Certification and Disclosure forms, together with a
completed Ownership Disclosure form, either electronically to [email protected], or regular mail at Chapter 51 Review
Unit, P.O. Box 039, 33 West State Street, 9th Floor, Trenton, NJ 08625. The agency should save the forms locally and keep the
original forms on file, and submit copies to the Chapter 51 Review Unit.
CH51.1 R1/21/2009
Page 3 of 3
52
Public Law 2005, Chapter 92
Formerly: Executive Order 129
In accordance with Public Law 2005, Chapter 92 (N.J.S.A . 52:34-13.2 et seq., superseding Executive O rder
129 (2004)) all bidders submitting a proposal shall be re quired to submit a Source Disclosure Certification
that all services will be perfor med in the United States. The bidder shall dis close the location by country
where services under the contract will be performed a nd any subcontracting of services un der the contract
and the location by country where any subcontracted services will be performed.
Public Law 2005, Chapter 92
Formerly: Executive Order 129
SOURCE DISCLOSURE CERTIFICATION FORM
Bidder: _____________________________________
I hereby certify and say:
I have personal knowledge of the facts set forth herein and am authorized to make this Certification on behalf
of the Bidder.
The Bidder subm its this Certification as part of a bi d proposal in response to the referenced solicitation
issued by the The Richard Stockton College of New Jersey, Office of Adm inistration and Finance, in
accordance with the requirements of Public Law 2005, Chapter 92, (N.J.S.A. 52:34-13.2 et seq., superseding
Executive Order 129 (2004)).
The following is a list
subcontractors.
Bidder or Subcontractor
of every location where services will be performed by
Description of Services
the bidder and all
Performance Location(s) by Country
Any changes to the information set forth in this Certification during the term of any contract awarded under
the referenced Project Number will be immediately reported by the Bidder to The Richard Stockton College
of New Jersey, PO Box 483, 10 W. Jimmie Leeds Road, Pomona, NJ 08240.
I understand that, after award of a contract to the Bidder, it is determined that the Bidder has shifted services
declared above to be provided within the United States to sources outside the United States, prior to a written
determination by The Richard Stockt on College of New Jersey , Office of Administration and Finance, that
extraordinary circumstances require the shift of servi ces or that the failure to shift the services would result
in economic hardship to The Richard Stockton College of New Jersey, the Bidder shall be d eemed in breach
of contract, which contract will be subject to termination for cause under its contract with the RSC.
53
I further understand that this Certificati on is subm itted on behalf of the Bidder in order to i nduce RSC to
accept a bid proposal, with knowledge that the State of New Jersey and RSC are relying upon the truth of the
statements contained herein.
I certify that, to the best of my knowledge and belief, the foregoing statements by me are true. I a m aware
that if any of the statements are willfully false, I am subject to punishment.
Bidder: ________________________________________
[Name of Organization or Entity]
By: ___________________________________________
Title: _____________________________
Print Name: ____________________________________
Date: _____________________________
54