1. society
2. work
3. contracts

TENDER
BIRLA INSTITUTE OF TECHNOLOGY,
Mesra, Ranchi
FOR
Supply & Installation of Auditorium Chairs
Auditorium Consultant
V N Purandare
124, Shaniwar Peth, Pune 411030
+91 9890922712
[email protected]
Office of:
The Registrar
Birla Institute of Technology
Mesra, Ranchi.
Contractor’s seal & signature
INVITATION FOR TENDER: Supply & installation of Auditorium Chairs
To
--------------------------------------------------------------------------------------------------------------------------------Dear Sir,
Sub: - Supply & installation of Auditorium Chairs
1) You are invited to submit your most competitive Tender along with qualification documents
for the following works:Brief Description of works
Supply & Installation of Auditorium chairs
Period of completion
160 days from the date of Works Order.
1) Tender forms will only be given to the contractors fulfilling the qualification norms & the will
again be verified on receiving the tenders.
2) To assist you in the preparation of your tender, we are enclosing the following:
Detailed Bill of Quantities
Instructions, Drawings & terms and conditions.
Draft agreement format, which will be used for finalizing the agreement for this work.
3) You are requested to provide your offer by the date & time specified by the office.
4) By submitting the tender, you agree & accept that the owner reserves the right to allocate
the work to most responsive bidder.
We look forward to receiving your tender and thank you for your interest in this project.
Yours Sincerely,
Sd/Birla Institute of Technology, Mesra, Ranchi,
Zarkhand
Contractor’s seal & signature
Instructions
SECTION –A
1) Scope of works
Birla Institute of Technology, Mesra, Ranchi (Employer), invites the tenders for the Supply &
Installation of Auditorium chairs as detailed in the table given bellows
Brief Description of works
Supply & Installation of Auditorium chairs
Period of completion
160 days from the date of Works Order.
2) Qualification: - You shall provide qualification information which includes :a) Total monetary value Supply & Installation of Auditorium chairs works performed for each
year of the last 3 years for works similar in nature of the present work.
b) Copy of Income tax return for last 3 years.
c) Details of any litigation, current or during the last 3 years in which the bidder is involved,
the parties concerned and disputed amount in each case.
3)
To qualify for award of the work: a) Should have satisfactorily executed in last three years or currently executing, as a main
contactor at least three auditorium assignments of auditorium seating 500 or more &
each having value not less than Rs. 25,00,000/- or at least two similar assignments of
auditorium seating 700 or more & each having value not less than Rs. 35,00,000/- or
one similar assignment of auditorium seating 1000 or more & value not less than Rs
50,00,000/- . self-certified copy of the certificate / P. O. from the concerned should be
attached
b) Joint ventures are not acceptable.
c) Even if pre-qualified, you are subject to be disqualified if:  made misleading or false representations in the forms, statements and attachments
submitted in proof of the qualification requirements; and/or
 record of poor performance such as abandoning the works, not properly completing
the contract, inordinate delays in completion, litigation history, or financial failures
etc.; and/or
4) Price
a) The contract shall be for the complete works as described in the bill of quantities,
drawing and technical specifications, corrections, if any, shall be made by crossing
out, initialing.
b) VAT & services tax is to be given separately and all duties, taxes and other levies shall
be included in the total price.
Contractor’s seal & signature
c) The rates quoted shall be fixed for the duration of the contract and shall not be subject
to adjustment on any account.
d) The rates should be quoted in Indian Rupees.
e) You shall bear all costs associated with the preparation and submission of this tender,
and the owner will in no case be responsible & liable for those costs.
f) On your own responsibility and risk you are encouraged to visit and examine the Site of
Works and its surroundings and obtain all information that may be necessary for
preparing the tender.
5) Submission of Tenders
a] One bidder can submit only one Tender. Submission of more than one Tender by shall
automatically lead to disqualification.
b] The tender should be submitted in 2 sealed envelopes, addressed to The Registrar, Birla
Institute of Technology, Mesra Ranchi.
One envelop, marked as “Technical Bid” will carry all the qualification documents, bidders
covering letter mentioning list of documents & D. D. s for cost of tender as well as EMD if any.
The other envelop marked as “Price Bid” will carry the price bid and the original tender with
signature & stamp on each & every page.
These two envelops should be sealed again in one big envelop.
All The envelopes will also bear the following identification :

Tender for “Supply & Installation of Auditorium chairs”
Name & Address of the bidder.
c] Tenders must be received in the office of the owner at above given address, not later than
the time and date specified.
d] Any tenders received after the deadline for submission, will be rejected & no communication
in this regard will be made.
6)
Validity
Tender shall remain valid not less than 45 days after the deadline date specified
for submission.
7)
Opening of Tenders
Tenders will be opened in the presence of consultants & owners.
8)
Information relating the evaluation & recommendations for the award of work shall not
be disclosed to any persons not officially concerned with the process, until the work is
awarded to most responsive bidder.
9)
Evaluation
Contractor’s seal & signature
The owner will evaluate & compare the tenders along with the samples determined to
be substantially responsive i.e. which
a)
b)
c)
10)
Meet the technical qualification criteria specified in clause 2&3 above
Are properly signed
Conform to the terms and conditions, specification & drawings without any
deviations.
Award of contract
The Employer will select the bidder whose tender has been determined to be
substantially responsive and who meets the specified qualification criteria.
Notwithstanding above, the Employer reserves the right to accept or reject any tender,
and/ or to cancel the entire process and reject all the tenders, at any time prior to the
award of work, without thereby incurring any liability or any obligation.
11)
Performance Security
5% amount of every running bill will be hold back by the owner as a performance
security. The same will be release on completion of Period of Maintenance.
12)
Period of Maintenance:
The auditorium chairs & classroom seating system should carry warranty minimum 3
years & service warranty of minimum 10 years. During the period warranty, the
contractor will be responsible for rectifying any defects in manufacturing as well as
working. This will be done by the contractor at his own expenses. During the period of
service warranty, contractor must provide the required service including the parts, for
this the cost of the part & travelling cost of the mechanic (by train at actuals) will be paid
by the institute.
However the security deposit will be refunded to contractor on completion of 1 year from
the date of handover.
…………………………..
Contractor’s seal & signature
QUALIFICATION INFORMATION
(To be supplied along with the tender)
1)
Name & address:
1.1)
Principal place of business :-
_______________________________
Power of attorney of signatory.
(Attach attested Xerox copy)
1.2)
Total value of Auditorium
Acoustics performed in the last
Three years (in Rs. Lac)
2012-2013 _____________________
2013-2014 ____________________
2014-2015 _____________________
1.3)
Work performed as prime contractor (in the same name) of a similar nature over the last
three years And Information about Existing commitments and on – going works:-
Use separate sheet
Enclose a certificate from engineer concerned along with PO.
1.4)
Name, address, & telephone No. of the bankers who may provide references if
contacted by the Employer.
1.5)
Information on litigation history if any on a separate sheet.
Contractor’s seal & signature
LETTER OF ACCEPTANCE CUM NOTICE TO PROCEED WITH THE WORK
Birla Institute of Technology
Mesra, Ranchi
Date :___________
To : _____________________________ (Name and address of the Contractor)
_____________________________
_____________________________
_____________________________
_____________________________
Dear Sirs,
This is to notify you that your Tender dated _____________________for execution of
the ____________________________________________________________ for the contract
price in Rupees ______________________________________________(Amount in words &
figures), is hereby accepted by us .
You are also requested to sign the agreement from & proceed with the work not latter
than______________________________under
the
instruction
of
the
engineer,
___________________________________& ensure its completion within the contract period.
Yours faithfully,
Birla Institute of Technology,
Mesra, Ranchi
Contractor’s seal & signature
ARTICLES OF AGREEMENT
1)
This deed of agreement is made in the form of agreement on _______________day
__________________ month _____________201___________, between (the referred to
as the first party) and _____________________ (Name of the contractor), S/O
___________________ resident of _________________(hereinafter referred to as the
second party), to execute the work of construction of _____________________
(hereinafter referred to as works) on the following terms & conditions.
2)
Cost of contract
The total cost of the works (hereinafter referred to as the “total cost”) is Rs._______as
reflected in Annexure -1.
3) Payments under its contract:
Payments to the second party for the work will be released by the First party in the
following manner:Mobilization advance
On pro-rata basis as per the R. A. bill(s)
of the contractor. Payable amount in
each R. A. bill should not be less than
Rs. 20,00,000
Final bill
On completion of the work & submission
of the completion report approved by
the consultant.
:
10% of the order value.
This will be adjusted in first 2 RA bills.
As per the certified bill of the contractor
based on the measurements along with
certification
As per the certified bill of the contractor
based on the measurements along with
certification
of
completion
to
the
satisfaction.
4) Payment will be made by the first party:
a) On the second party submitting an invoice for an equivalent amount along with the
certified copy of the bill of quantities & measurements;
b) On certification of the invoice by the engineer &/ or consultant.
c) Payment will be given within 15 days of certification of the RA bills & within 1 month of
certification of the final bill, any further & unjustified delay will carry the simple interest of
0.66% PM.
d) Necessary deductions towards taxes, govt. dues, and security deposits will be done at
every payment.
e) Any delay in completion of the work, without any justified reason, will carry a penalty of
0.5% of order value per week, maximum up to 5%. On exceeding this limit the owner can
terminate the work without giving any reason.
5) Notice by Contractor to Engineer
The second party, on the works reaching each stage of construction, issue a notice to the
first party or the Engineer nominated by the first party (who is responsible for supervising
the contractor, administering the contract, certifying the payment due to the contractor,
issuing & valuing variations to the contract, awarding extensions of time etc.) to visit the
Contractor’s seal & signature
site for certification of the stage completion. Within 15 days of the receipt of such notice,
the first party or the contractor nominated by it, will ensure issue of stage completion
certificate after due verification.
6) Completion time
The work should be completed in specified time from the date of this Agreement. In
exceptional circumstances, the time period stated in this clause may be extended in
writing by mutual consent of both parties.
7) If any of the compensation events mentioned below would prevent the work being
completed by the intended completion date, the first party will decide on the intended
completion date being extended by a suitable period :
a.
b.
c.
d.
e.
The first party does not give access to the site or a part thereof by the agreed
period.
The first party orders a delay or does not issue completed drawing, specifications
or instructions for execution of the work on time.
Ground conditions are substantially more adverse than could reasonably have
been assumed before issue of letter of from information provided to second party or
from visual inspection of the site.
Payments due to the second party, are delayed without reason.
Certification for stage completion of the work is delayed unreasonably.
8) Any willful delay on the part of the second party in completing the project within the
stipulated period will render him liable to pay liquidated damages. @ 0.5 % of the total work
value per weak which will be deducted from payment due to him. The first party may cancel
the contract and take recourse to such other action as deemed appropriate, once the total
amount of liquidated damages exceeds 5% of the contract amount.
9) Duties & responsibilities of the first party
a) The first party shall be responsible for providing regular & frequent supervision & guidance
to the second party for carrying out the works as per specifications. This will include written
guidelines & regular site visit of the authorized personal of the first party, for checking quality of
material & construction to ensure that it is as per the norms.
b) The first party shall provide drawing, specifications & guidelines to the second party for the
proposed work.
c) Possession of the site will be handed over to the second party within two days of signing of
the agreement.
d) The engineer or such other person as may be authorized by the first party shall be meeting
once in a week where a second party or his representative at site will submit the latest
information including progress report & difficulties if any, in the execution of the work. The
whole team may jointly inspect the site on a particular day to take stock of activities.
e) The engineer shall record his observations/instructions at the time of his site visit in a site
register maintained by the second party. The second party will carry out the instructions &
promptly rectify any deviations pointed out by the engineer. If the deviations are not rectified,
within the time specified in the engineer’s notice, the first party as well as the engineer
nominated, may instruct stoppage & get the work rectified at the cost of the second party.
Contractor’s seal & signature
10 Duties & Responsibility of the second party.
The second party shall:
a) Take up the works & arrange for its completion within the time period stipulated.
b) Employ suitable skilled persons to carry out the works;
c) Regularly supervise & monitor the progress of work;
d) Abide by the technical suggestions / direction of supervisory personal including
engineers etc. regarding building construction;
e) Bye responsible for bringing any discrepancy to the notice of the representative of
the first party & seek necessary clarification;
f)
Ensure that work is carried out in accordance with specifications, drawing & within
the total of the contract amount without any cost escalation;
g) Keep the first party informed about the progress of work;
h) Be responsible for all security & watch & warned arrangements at site till handing
over of the building to the first party
i)
Maintain necessary insurance against loss of material / cash etc. or workman
disability compensation claims of the personal deployed on the works as well as
third party claims.
j)
Pay all duties, taxes and other levies payable by construction agencies as per law
under the contract (First party will effect deduction from bill in respect of such taxes
as may be imposed as may be under the law)
10. Variations / Extra Items
The works shall be carried out by the second party in accordance with the approved
drawing & specifications or directives from the engineer in –charge. However if, on
account of site condition or any other factors, variations are considered necessary, the
following procedure shall be followed:
a) The second party shall provide engineer with a tender for carrying out the variation
when requested to do so by the engineer .The engineer shall assess the tender
which shall be given within seven days of the request before the variation is ordered.
b) If the tender given by second party is unreasonable, the engineer may order the
variation & make a change to the contract price which shall be base on engineer’s
own forecast of the effects of the variation on the contractor’s costs.
c) The second party shall not entitled to additional payment for cost which could have
been avoided by giving early warning.
11. Securities
The Performance Security can be released on completion of the work against the bank
guarantee of equal amount for the period of 12 months.
12. Termination
13.1) The Employer may terminate the contract if the other party causes a fundamental breach
of the contract.
13.2) Fundamental breach of contract includes, but shall not be limited to the following
(a) The contractor has stopped the work for 7 days & stoppage has not been authorized
by the engineer.
(b) The contractor has become bankrupt or goes into liquidation other than for a
reconstruction or amalgamation;
Contractor’s seal & signature
(c)
(d)
The engineer gives notice that failure to correct a particular defect is a fundamental
branch of contact & the contractor fails to correct it within a reasonable period of
time determined by the engineer.
The contractor does not maintain proper safety & security at the site.
13.3) Notwithstanding the above, the Employer may term the contract for
convenience.
13.4) If the contract is terminated the contractor shall stop work immediately, make the site
safe & secure & leave the site as soon as reasonably possible.
14. Payment upon Termination
14.1 If the contractor is terminated because of a fundamental branch of contract by the
contractor, the engineer shall issue a certificate for the value of the work done less advance
payment received up to the date of the issue of the certificate, less than other recoveries due
in terms of the contract, less taxes due to deducted at sources as per applicable law.
14.2 If the contract is terminated at the Employer‘s convenience, the engineer / consultant
shall issue a certificate for the value of the work done, the responsible cost of removal of
equipment, repatriation of the contractor‘s personal employed solely on the works & the
contractor’s costs of protecting & securing the work & less advance payments received up to
the date of the certificate, less other recoveries due in terms of the contract & less taxes due to
be deducted at source as per applicable law.
15. Dispute settlement
If over the works, any dispute arises between the two parties, relating to any aspects of
this Agreement, the parties shall first attempt to settle the dispute through mutual &
amicable construction.
In the event of agreement not being reached, the matter will be referred for arbitration
by a sole Arbitrator not below the level of retired Superintending Engineer, PWD to be
appointed by the first party. The Arbitration will be conducted in accordance with the
Arbitration & Conciliation Act 1996. the decision of the Arbitrator shall be final & binding
on both the parties.
16.
SPECIAL CONDITIONS
1. For Technical data / detail & specifications if in doubt /unclear /mismatch, the same are
to be clarified with the Acoustic Consultants.
2. The client reserves the option to allot the work partly or totally to single or different
Contractors. The Client also reserves the right to supply some of the material. The
scope of work for such items will be limited to erection only.
3. The Client / Consultants reserve the right to call explanations from any bidder regarding
the calculations / clarifications on any details. They may also visit the office of the bidder
/ various works carried out by him. Cooperation in this regard is envisaged form the
bidder.
4. The bill of quantities indicated in this tender are approximate & are liable to change at
the discretion of the client / Consultants. Any variation in quantities will not be applicable
for change/modification in quoted rates.
Contractor’s seal & signature
5. The Contractor will be responsible for the due & proper execution of all the works as per
the terms & conditions. The contracting agency should study the design details and
understand clearly prior to quoting. The responsibility of performance will be with the
Contractor.
6. The contractor may have to use additional supports, materials, accessories, hardware,
labor, equipments etc, for proper execution & performance, required stability of
complete system, fulfilling interior design requirements, following best engineering
practice, executing the additional instructions given by the consultants or employer
during the work. No additional cost will be paid for this.
7. The bidder shall make no changes in the tender form or in the specifications &
schedule. The bidder may however submit alternative proposals, in separate
enclosures, indicating any variation whichever they feel is beneficial. Calculations,
salient features, advantages, economics & drawings shall back the same. Acceptance
or rejection of such alternate proposal will be the right of the employer & consultants.
8. The Consultant / their representatives shall have access to the workshop
/Manufacturing facilities of the bidder so as to assure themselves of the quality of the
material & workmanship.
9. The measurement given in drawing is subject to verification at site. In case of any
discrepancy, the same shall be brought to the notice of both, the engineer in charge &
Consultants for the decision.
10. The mock up: the bidder will have to submit one sample of the chair along with the
tender, in the office of employer for inspection & the sample of the contractor will remain
with the owner till completion of the work..
11. In order to complete the work, within the time limit of the tender, the contractor may
have to work in more than one shift.
12. The contractor shall make their own arrangements for security of their materials / tools
etc.
13. In case of not availability of specified materials in the market, the contractor may
substitute by equivalent materials of same quality & properties, after duly approved by
the Consultant.
14. Client / Consultants reserves the right to split the items and scope of work before
awarding the contract without assigning any reason thereof.
15. In case of any controversy, the decision of the Consultant shall be final & binding on
contractor.
16. Verbal instructions given by the Consultant, if any, will be confirmed in writing by the
contractor within 7 days & before execution thereof.
17. At least one engineer, of the contractor, capable of understanding all the technical
points & act accordingly, should be available on site all the time.
18. The contractor along with his technical staff should be present at site at the time of sitevisit of the Consultants & whenever is needed.
19. In case of conflict in specifications or terms, between tender, drawings, general
engineering practice, national & international codes, more stringent among all will be
applicable.
17. TECHNICAL SPECIFICATIONS
The auditorium chairs should be of following specifications
 Tip Up Seat auditorium chair.
Contractor’s seal & signature











Powder Coated Heavy duty MS Stand.
Individually molded, ergonomically designed seat and back cushions.
Back & seat Cushion –molded polyurethane foam cushion. PU foam density.
Molded Polyurethane Foam manufactured in certified ISO 9001 facility to ensure
consistency in density for longevity .
Upholstered in Foam laminated stretch Fabric for clean finish and soft comfortable feel
as per the color & pattern selected.
Seat and Back fully Upholstered offering enhanced acoustic absorption properties.
Wooden or PU armrest.
Mounted with 8/10 mm x 75 mm Anchor fasteners.
Total chair height should not be more than 1030 mm.
Indicative drawing is given.
Approved vendors Theater Solutions India, Pen-workers, Godrej, Wipro
The Lecture theatre seating should be of following specifications
 Tip Up Seat wooden chair with laminated table top .
 Powder Coated Heavy duty MS frame.
 Mounted with 8/10 mm x 75 mm Anchor fasteners.
 Indicative drawing is given.
 Approved vendors Theater Solutions, Pen-workers, Godrej, Wipro
Contractor’s seal & signature
The Tender
(To be completed by the contractor)
Description of the works: Supply & Installation of Auditorium chairs
To:
Birla Institute of Technology, Mesra, Ranchi
Subject: Auditorium Acoustics & Interior.
Reference: Letter No.__________________ dated_______________from____________
Sir,
We offer to execute the works described in your letter referred to above in accordance with the
Conditions of contract enclosed therewith at a total contract price of (Including all duties &
taxes)
Rs.**________________________________________________________(In figures)
Rs. ________________________________________________________ (In words)
This tender and your written acceptance of it shall constitute a binding contract between us.
We understand & accept that you are not bound to accept the lowest tender you receive.
We hereby confirm that this tender is valid for 45 days.
Yours faithfully,
Authorized Signature:
Name & Title of Signatory
Name of Bidder
Address
Date :___________________
:_________________________________________________
:_________________________________________________
:_________________________________________________
Contractor’s seal & signature
B. O Q.: Supply & Installation of Auditorium chairs
BIT Ranchi Golden Jubilee Auditorium: Auditorium Chairs
Sr. No
1
Description
Qty
Rate
Amount
Rate
Amount
Rate
Amount
Providing & fixing in position, heavy duty fully upholstered
2500
Auditorium chairs 550 mm c to c tip-up type Thin back type
Golden Jubilee Auditorium Chairs Total
BIT Ranchi CAT Auditorium: Auditorium Chairs
Sr. No
Description
Qty
1
Providing & fixing in position, heavy duty fully upholstered
Auditorium chairs 550 mm c to c tip-up type Thin back type
300
CAT Auditorium Chairs Total
BIT Ranchi Lecture Theatre: Classroom Seating
Sr. No
1
Description
Providing & fixing in position, classroom desk of wooden
Table-top & wooden tip-up chair as per approved design.
Qty
320
Lecture Theatre seating Total
Total cost Auditorium Chairs
Gross Total cost before Vat & Service tax: Rs. ________________
In Words: Rs.___________________________________________________________
Rate
Vat applicable
Vat applicable
Vat applicable
Service tax applicable @ the rate
Gross Total Cost Auditorium Chairs
On amount
Tax amount
%
%
%
%
Rate of the taxes will apply as per government rules & at the time of billing.
Attach separate sheet explaining the current tax structure.
Gross Total cost including VAT & Sr. Tax: Rs. ________________
In Words: Rs.___________________________________________________________
Contractor’s seal & signature