Tender For Furnishing Works At BANK OF INDIA / RAIGAD ZONE TALA BRANCH, 1st Floor, at & Post Tala, Tal. Mangaon, Dist. Raigad. Maharashtra. Name of Architect RAJVILAS GADKARI Architects and Interior Designers 1B, Jai Mata Di CHS Ltd, VN Purav marg, Kumbharwada, Chembur East, Mumbai- 71 M; 98210 49457, T/F: 2528 9963, email: [email protected] October ‘14 Tender For Furnishing Works At BANK OF INDIA / RAIGAD ZONE TALA BRANCH, 1st Floor, at & Post Tala, Tal. Mangaon, Dist. Raigad. Maharashtra. TENDER NOTICE : 1 INSTRUCTIONS TO TENDERS : 2-3 TENDER & APPENDIX : 4-5 SPECIAL CONDITIONS OF CONTRACTS : 6- 9 SPECIFICATIONS : 10 - 16 BILL OF QUANTITIES : 17 - 24 DRAWINGS : 25 1 T E N D E R N O T I CE 1. Sealed item rate Tenders are invited from Empanelled Furnishing Contractors Contractor s having adequate resources and experiences in the execution of similar works of comparable magnitude: a) Name and nature of works : Furnishing Works (Carpentry, Civil, False-Ceiling, Painting etc) b) Time for completion : 45 days. c) Cost of tender papers : Nil 2. Tender papers shall be available for issue on any working day from 10AM to 5PM from at Bank Of India, Raigad Zonal Office, 2nd Floor, Hotel Meera Madhav, Opp. ST Stand, Alibag, Raigad- 402 201. 3. Sealed Tenders papers shall be submitted latest by 03 PM on Bank Of India, Raigad Zonal Office, 2nd Floor, Hotel Meera Madhav, Opp. ST stand, Alibag, Dist Raigad – 402 201. 15/10/2014 at 4. Tender shall be valid for a period of 90 days from the date of opening. 5. Sealed Tenders shall be opened at Bank Of India, Raigad Zonal Office, Madhav, Opp ST Stand, Alibag, Dist. Raigad – 402, 201 2nd floor, Hotel Meera on 16/10/2014 at 04 PM. 6. The BANK reserves the right to reject any or all the tenders and accept the lowest or any other tender or award the different parts of the tender by splitting them to different tenders without assigning any reason whatsoever. 7. Contractors having three or more projects on hand will not be considered eligible. 8. Please collect detail drawings from Bank Of India, Raigad Zonal Office, Madhav, Opp ST Stand, Alibag, Dist. Raigad – 402, 201 2nd floor, Hotel Meera - The Zonal Manager, Bank Of India Raigad Zonal Office, 2nd Floor, Hotel Meera Madhav, Opp. ST Stand, Alibag, Dist: Raigad- 402 201, 2 INSTRUCTIONS TO TENDERERS 1. The Tender shall be submitted in accordance with these instructions and any Tender not conforming thereto is liable to be rejected. These instructions form part of the Tender and the Contract. 2. No additions/alternations in the form of the Tender or in the Schedule of Quantities and no additions in the shape of special stipulation etc. are permitted. Tender which do not fulfill any or all of the above conditions or are incomplete in any respect are liable to be summarily rejected. 3. The contractor should particularly note the units on which the rates are based. In case the amount shown in the last column as worked out by the tenderer differs from that worked out from the quantity and quoted rate, the amount based on the rate and the quantity will be taken as correct. In case there is a difference between the rates in figures and words, the rate adopted by the contractor for working out the amount of the item will be taken as correct. In other cases, the final rates adopted will be the lower of the two. No change in units shall be allowed. 4. Acceptance of the ender will rest with the competent authority (from the bank) that reserves the right to reject any or all Tenders without assigning any reason therefore. 5. The tenderer whose tender is accepted will have to enter into regular agreement within 7 days from date of receipt of intimations of acceptance of the Tend er and abide by all rules and regulations mentioned therein. he amount of Earnest Money shall be forfeited if after acceptance of the Tender, the Contractor fails to execute the agreement within 7 days of the date of work order. 6. The tenderer shall have assum ed to have carefully examined the site, conditions and specifications of the contract, and to have fully acquainted himself with all details of site location, site conditions and in general all necessary inform ation and data pertaining to the work prior to tendering for the work. 7. If a firm or company is submitting the tender, it should mention in its forwarding letter the names of all partners, directors, etc. The Tender shall be filled in, signed with all particulars complete and submitted by one duly authorized to do so. 8. Conditional Tenders are liable to be rejected. Tenderer are advised to avoid putting conditions that are at variance with the terms and conditions already stipulated in the tender or quote conditional rates for any of the items in the Schedule of Quantities. 9. Corrections, if made, shall be made neatly and clearly and duly attested by one authorised to do so. 3 10. The Tenderer may in the forwarding letter mention any points which he may wish to make clear, but right is reserved by the BANK to reject the same if the tender becomes conditional. 11. The Tender will be liable to be rejected outright if: a) The Tenderer proposes any alternations in the work specified in the Tender, in the time allowed for execution and any other conditions. b) Any of the pages of the Tender are removed / replaced. c) All corrections and additions or pasted slips are not initialed by the Tenderer. d) The Tender is not complete in all respects. 12. The Tenderer shall complete and submit the following for his tender to be considered as bonafide: a) Form of Tender and Appendix. b) Bill of quantities, each page duly signed. c) List of plant/equipment and personnel to be employed on the said works. d) Requirement of power, water and extent of storage space, etc. for the duration of the works. 13. The Tender documents duly completed in all respects along with other accompanying documents shall be submitted in one envelope sealed any super scribed. TENDER FOR RENOVATION WORKS AT BANK OF INDIA TALA BRANCH, CONTRACTORS NAME & ADDRESS: DATE & TIME OF SUBMISSION 4 T E N D E R The Zonal Manager, Bank Of India Raigad Zonal Office, 2nd floor, Hotel Meera Madhav, Opp ST Stand, Alibag, Dist: Raigad, 402 201 Dear Sir, TENDER FOR RENOVATION WORKS AT BANK OF INDIA, TALA Branch having inspected the site and having examined the conditions of contract, – named Special Conditions of Contract, Specifications and Bill of Quantities for the above work, we the undersigned offer to execute and maintain the entire works for the sum of Rupees _________________________________________________________________ Or such other sum may be ascertained in accordance with the said Conditions, Special Conditions of Contract, Specifications, Bill of quantities and Appendix hereto. Our tender is accompanied with Earnest Money as required in the instructions to tenderers. If our tender is accepted, the Earnest Money along with additional cheque to make the total 2% of tender value to constitute the Initial Security Deposit towards due and proper performance of the contract. We undertake if our tender is accepted, to commence the works and complete the same within the time stipulated in the Appendix. We agree to abide by this tender for a period specified in the Tender Notice. It shall remain binding on us and may be accepted at any time before the expiry of that period and / or before the expiry of any further period extended by mutual consent. In case of any default by us in our obligations above, we acknowledge you are at liberty to forfeit the Earnest Money deposited herewith. Until and unless a formal agreement is prepared and executed this Tender together with your written acceptance thereof, shall constitute a binding contract between us together with all the general Conditions of Contract, Special Conditions of Contract, Specifications, Bill of Quantities and Price, and Instructions to Tenders. We understand that you are not bound to accept the lowest or any other Tender you receive. Note : 1. The Appendix forms part of the Tender. 2. All Blanks to be filled in. 5 APPENDIX TO TENDER 1. Earnest Money : 1% of Tender Value pay order / D.D. fvg. „BANK OF INDIA 2. Security Deposit a) Initial b) During maintenance Period : 2% of tender amount. : @ 4% of value of work 3. Insurance a) Workmen s Compensation Insurance : As required by law. 4. Period of commencements of works from date of acceptance : 7 days. 5. Time for completion of work : 45 days maximum. 6. Amount of liquidated Damages : 0.5% of value of contract per week . 7. Period of maintenance (Defects Liability Period) : 12 months from certified completion. 8. Amount of interim Certificate : Rs. 2,00,000/- minimum 9. Percentage of Retention From Interim Certificates Inclusive of Initial Security Deposit : 8% 10. Time within which payment Shall be m ade after Architect s certification : Interim Bill - 7 days : Final Bill - 30 days Contractor s Signature: Date: 6 SPECIAL CONDITIONS OF CONTRACT 1. The works are to be carried out outside and inside the banking hall. The tenderer should visit the site in order to ascertain the extent of work, difficulties at site, storage space available, and other site conditions. 2. The works include renovation of vital areas of the operational branch. Works will need to be so planned that minimum disturbance is caused to the bank staff & customers. Works plans shall be devised keeping this is mind and got approved by the Architect. 3. The contractor whose tender is accepted, shall within 7 days of receipt of written acceptance of the tender enter into a written contract with the Bank for the due execution of the works by signing an agreement in accordance with the draft agreement, including special conditions, schedule of quantities and other conditions attached. Otherwise, the written acceptance (Work Order) by the Bank will constitute a binding agreement between the Bank and Contractor so tendering, whether such formal contract is or is not subsequently entered into. 4. Unless otherwise specified, the rates quoted in the tender shall include all charges for temporary partitions, counters, tables, materials, service charges, temporary plumbing, hire of any tools and plants, shed for materials if required by the contractor and such other general works Mentioned in the specifications. The rates quoted by the tenderer in the schedule of rates shall be for finished work. The rates shall be inclusive of Sales tax, Works Contract tax, Oetroi duty or any other duty levied by the Government or public bodies. The rates shall be firm and shall not be subject to any variation, labour condition, etc. and shall hold good till completion of the work. 5. Time shall be considered as essence of the contract and the Contractor shall within 7 days of receipt of Work Order ubmit to the Consultant a bar chart / schedule program for the progress and completion of the work within the schedule time period. This progress shall be binding on the Contractor. Deviations in the program if any, will be made only with prior approval of the Employer and Architect. 6. Contractors shall arrange payment to the suppliers irrespective of banks clearance of bills. Where possible, the contractor shall be provided space in the stilts and / or garages for storage of materials for the duration of the works. Security of the materials shall be the contractor s responsibility. 7. The materials purchased from outside by the contractor and brought to site shall, if the Architect / Bank so desire, be got tested and certified by a recognized testing laboratory to the satisfaction of the Architect /Bank before such materials are used on the work. The testing charges shall be borne entirely by the contractor. 7 8. The successful tenderer shall cooperate with the other agencies viz. power wiring, data cabling, A/c contractor etc. if engaged by the Bank for due and proper Execution of the respective works. 9. In case extra items of work are required by the branch, rates for such items will be decided on the basis of similar items already xisting in the tender or as per prevailing market rates for materials and labour with a mark-up of twenty percent for overheads and profits, whichever is lower. The works will be executed only after Zonal Office permits. Decision of the Z. O. in this shall be final. . 10. The bank shall provide the following free of cost to contractor: a) Water supply for the works at one point of work sit Further storage tank and distribution shall be the Contractor s responsibility. b) Electric power supply at one point at site free of cost to the Contractor. The contractor shall provide his own distribution and ensure there is no misuse. 11. Contractor shall take all precautions to cover all computers printers, monitors etc., glass and windowpanes to prevent damage. Damage, if any shall be made good at no extra cost to bank. 12. Unless otherwise specified, all relevant codes and standards published by the Indian Standards Institution shall apply and govern in respect of design, workmanship quality and properties of materials, testing and measurements. 13. Safety Measure: The Contractor shall organize his operations in a workman like manner and take all necessary precautions to provide safety and prevent accidents at site both to persons and property. The Architect shall have the power to require the Contractor to adopt such measures. Bank / Architect shall not be responsible for any cost & consequences resulting from non- compliance of safety requirements. Contractor shall indemnify the Bank against any breach and / or penal action. 14. All dism antling work shall be done with carefully. Chipping of RCC elements will not be allowed. Damage caused due to negligence on the part of the Contractor as determined by the Architect shall be the responsibility of the Contractor and he shall rectify the same at no extra cost to the Bank. 15. Problems arising out of site conditions, etc. should be immediately reported to the Architect for suitable precautionary / rectification measures. Exact repairs shall be decided at site by the Architect & Bank during the site inspection and carried out accordingly by the Contractor only after H. O. approval. 8 16. The Contractor shall comply with all rules and regulations of Workmen s Compensation Act. The Contractor shall take necessary insurance to cover the risk under the said Act and shall keep the same in force during the currency of the Contract. The Bank will be entitled to recover all losses and damages on account of such claim s. The Contractor shall indemnify the Bank against such claims. 17. The Contractor shall appoint a full time competent supervisor for the full duration of the works. The supervisor shall be preferably an interior designer with at least 3 years experience in similar works and approved by the Architect. – skilled and 18. The Contractor shall em ploy requisite supervisors, skilled, semi unskilled workmen for the works. As a security measure each shall be provided an identity card by the Contractor for easy identification. 19. A license holder with adequate experience shall carry out temporary electrical connection works. 20. The Contractor shall permit use of scaffolding or other access provided at site for use by other agencies that are appointed by the Bank for carrying out related works. 21. The entire works should be completed within the prescribed time. Damages will be imposed on the Contractor in case of persistent delay. This amount shall be deducted from pending Bills / dues to the Contractor. (Ref. Item no. 6 Appendix) 22. The overall work in value and contents may be increased or decreased without any increase in rates. Additional item shall however be allowed for additional works. 23. The Contractor shall submit detailed bills for complete works periodically. The value of each bill should not exceed the value mentioned in item no. 8 of Appendix to Tender. 24. The time period specified is including that required for the painting works. Painting shall be commenced along with other works. 25. RETENTION: An amount equal to 8 percent of each bill shall be deducted as retention amount. The Bank will retain this amount as a token guarantee against defects in the works. This amount will be released after the completion of the Defects Liability period. 26. SUB- CONTRACTING: Preference will be given to those who will not sub contract the works. In case the contractor wished to sub-contract specific works viz. carpentry, flooring, false-ceiling, aluminum windows, painting etc., he shall obtain written consent from the Bank before commencing the works. 9 27. Proper scaffolding with all horizontal members above 6 ½ feet from G/L shall be used for the works of false ceiling. 28. The Contractor shall ensure proper cleaning of the work areas on a daily basis. All drains and pathways shall also be kept clean and operative at no extra cost to the Bank. 29. The following should be noted: Bank shall mean: Bank Of India Raigad Zonal Office, 2nd floor, Hotel Meera Madhav, Opp. ST Stand, Alibag, Dist: Raigad- 402 201. Consultant / Architect shall mean M/s Rajvilas D. Gadkari, Architects & Interior Designers. Contractor s Signature: Date: 10 SPECIFICATIONS FOR GENERAL WORKS This specification covers the general requirement for general building works viz. masonry, plastering, flooring, protection, waterproofing, doors, painting and such other related works forming part of this job, which may be required to be carried out though not specifically mentioned above. The Contractor shall furnish all materials, labour, tools plants, any and everything necessary for carrying out the work. 01. BRICKWORK: a) Bricks shall conform to the relevant Indian Standards. They shall be sound, hard, homogenous in texture, well burnt, table molded, deep red, cherry or copper coloured, of regular shape and size and shall have sharp and square edges and th of their weight when parallel faces. They shall not absorb water more than 1/6 soaked in water for more than 24 hours. Bricks shall have a minimum crushing strength of 50 kg/Sq cm unless otherwise noted in the drawings. The classes and quality of bricks shall be as laid down in IS: 3102 and their sizes as per IS: 1077. If demanded, brick sam ples may be got tested as per IS: 3495. b) Mortar for brick masonry shall be prepared as per IS: 2250. The sand shall be free from clay, shale, loam, alkali and organic matter. If required the sand shall be washed till it is free of any contamination. The mortar once prepared shall be used within 45 minutes of mixing. Mortar left unused in the specified period shall be rejected. c) All bricks shall be thoroughly soaked in clean water for at least one hour im mediately before being laid. Brick work 230 mm and over shall be laid in English Bond unless otherwise specified. 115 mm brickwork shall be laid with stretchers. Brick shall be laid with frogs uppermost. All brickwork shall be plumb, square and true to dimension shown. Vertical joints in alternate courses shall come directly one over the other and be in line. Horizontal course shall be leveled. d) Workmanship shall conform to IS: 2212. Bricks shall be so laid that all joints are well filled with mortar. The thickness of joints shall not be less than 6 mm and not more than 10 mm. The face joints shall be raked to a minimum depth of 12 mm when the mortar is still green, so as to provide a proper key for the plaster or pointing to be done. e) Measurement shall be sq. ft. of brickwork as per site measurements. 11 02. CEMENT PLASTER WORK: a) The surface to be rendered shall be washed with clean water, free from all dirt, grease, loose material etc. and thoroughly wetted for 6 hours before plastering work is commenced. Concrete surfaces to be rendered will however be kept dry. b) The proportioning of the mortar shall be as specified in the respective items of work. The quality of cement sand and water shall be as per relevant Indian Standard. The mortar thus mixed shall be used immediately and in no case be allowed to stand for more than 30 minutes after mixing with water. If required by specifications, waterproofing compound in the required quantity shall be added to the mortar. c) Curing of the plaster shall be started as soon as the applied plaster has hardened enough so as not to get damaged. Curing shall be done by continuously applying water in a fine spray and shall be carried out for at least 7 days. d) Interior plaster: This plaster shall be laid in a single coat of 10 mm thickness. The mortar dashed on the prepared surface with a trowel shall be finished with neeru (slaked fat lime). e) Exterior Plaster: This shall be carried out in 2 layers, the first layer being 10 mm thick and the second being 6 mm thick. The first or scratch coat shall be cured for at least 7 days and then allowed to dry. Before application of the second coat the scratch coat shall be evenly damped. The second coat shall be applied from top to bottom and without any joints. The sand for finishing work shall be of even coarse size so as to get an even finish on sponging. f) Measurement: The measurement shall be taken by taking the projected surface of the area plastered after making necessary deductions for openings, doors, window, etc. The actual plasterwork carried out on jambs of doors, windows, openings shall be measured and added. Plasterwork carried out on surface of items of work, which include smooth/form finished, shall not be taken into account. 12 03. WATERPROOFING ADMIXTURES: If directed by the Architect, the Contractor shall use approved waterproofing admixtures made by reputed manufacture in concrete or plaster work. The quantity to be used etc. shall be in accordance with the manufacturer s instructions subject to the approval of the Engineer. These admixtures shall not contain calcium chloride unless specifically allowed by the Engineer and shall conform to IS: 2645. Payment shall be by actual quantity of such admixture used unless it is already covered in the rates for the work concerned. 05. FLOORING: The flooring material will be as specified in the bill of quantities. Measurement for flooring shall be clear between the finished surfaces. Deductions shall be made for columns, projections, equipment foundations, openings, etc. 06. CARPENTRY: All materials viz: plywood, laminate, glass, granite, adhesives, timber etc. should be as per specification. 07. PAINTING: Paint to be used for the various items of work should be of approved make and colour. The actual quantity of work carried out will be measured in square feet after making deduction for openings etc. and shall be paid for unless the contract item rate in inclusive of painting. a) White wash: The surface is to be thoroughly cleaned before the white wash is applied. Ordinary fat lime of good quality shall be slaked with an excess of water for at least 2 days. This shall then be strained through a cloth and 2 kg of clean gum added for every Cu.M of lime. b) Colour wash: Necessary and approved colour shall be added to the white wash (above). Only wash sufficient for the day s work shall be prepared. 13 c) Distempering: The surface to be treated shall be thoroughly cleaned of all dirt and loose particles, etc. Inequalities and holes shall be filled with gypsum , which should be allowed to set hard before distemper is applied. A broad stiff brush in two coats shall apply distemper of approved make over a coat of primer. The first coat shall be of a lighter tint. Water bound and oil bound distemper shall conform to the requirements of IS: 427 and IS: 428 respectively. d) Cement Paint: Cement paint of approved quality and colour to be applied as specified by the manufacturer in 2/3 coats externally on the building. The base surface shall be brushed, cleaned and wetted before the application of cement paint. Each coat of paint shall be cured as specified by the manufacturer. a) Plastic Emulsion: All uneven surfaces shall be made good by use of putty of appropriate quality after the surface has been thoroughly cleaned of all dust, dirt and sand papered. One coat of primer and two coats of emulsion paint shall be applied. Workmanship shall conform to the requirements of IS: 2395. 08. ANTI TERMITE TREATMENT A comprehensive treatment around the buildings in the mounds and soil to create a chemical barrier between the ground from where the termites come and woodwork & other cellulose materials in the building. The treatment shall conform to the following: IS: 6313 (Part I), 1971 – Anti termite Measures in Buildings IS: 6313 (Part II), 1971 – Pre-constructional chemical Treatment Measures. IS: 6313 (Part III), 1971 – Treatment for existing structures The measurement for payment shall be the plinth area of all the buildings but will include for treatment to all doors. Windows, battens and other wood-work coming within the entire building. 14 07. GLAZING: Glass shall be free from bubbles, air holes, scratches and other defects. The glass should be cut accurately and fixed into position using glazing bands. All glasses broken or cracked during progress of works are to be reinstalled. All glasses to be cleaned from both sides and perfect at completion of the works. 08. ALUMINIUM WINDOWS & DOORS: Windows shall be made as per the drawings.The sections shall be anodized aluminum of approved quality and make (Jindal, Geeta or equivalent) of heavy type. The rate shall include the necessary framework, transoms, mullions etc as per the drawings. It shall also cover screws for anchoring, clips, tracks, beading, louver blades, rubber gaskets, provisions for fixing air conditioners (if required) and filling all gaps with appropriate sealant, etc com plete. Hinges & handles where required shall be of heavy-duty stainless steel or brass. Stoppers shall be in heavy-duty aluminum. Unless otherwise specified, 5.5 mm thick clear glass shall be used for glazing. 09. MILD STEEL GRILLS: Mild steel of approved quality shall be used for fabricating grills as per the drawings. The rate shall include all necessary anchors, flats, drilling, nailing, anchoring, etc necessary for fixing the grills on the walls or windows as the case may be. It shall also include – 1 coat cleaning, scrapping and applying 2 cleats of approved quality red oxide primer before fixing and 1 coat after fixing the grills in position. The area covered after fixing in position, excluding flats and anchors, shall be measured for payment. GENERAL REPAIRS This covers the general requirem ents of items involved in general repairs viz breaking and chiseling: surface preparation and treatment; restoration and curing, etc. Since there is an element of judgment and actual extent of deterioration involved, definite instructions on these can be given only at site during actual execution. 01 Scaffolding: Scaffolding shall be safe and erect. Under no circumstances will holes be allowed to be made in the walls to support the scaffolding. 02 Sand: Sand for concrete and plaster mortar shall be only river sand of proper gradations. Silt and other impurities must not exceed 4 percent. Improper sand shall be immediately rem oved from the site and the decision of the consultant shall be final. 03 Curing: New concrete shall be maintained damp for a period of 2 weeks minimum. New plaster shall be cured at least 3 times a day for a period not less than 10 days. The 1st coat of plaster shall be cured for a period not less than 3 days. If required the surface shall be maintained damp using a wet Hessian cloth. 15 RECOMMENDED BRANDS: Unless otherwise approved the following brands shall be used for these works: FURNISHING 1. Timber for door frames, Shutters, styles, mullions, Skirting fascia, decorative Molding, lipping etc. 2. CP Teak 1 st Quality 3. Plywood a) Commercial b) Marine Grade BTC or as specified. Timber for concealed work Sarda Plywood Duro Ply (MR Grade), Green Ply Ecotech (MR Grade), Prince ply( Ultra), URO (MR Grade) -do- 4. Laminate Greenlam 5. Locks Godrej. 6. Screws GWK / Nettlefold 7. Adhesive Fevicol 8. Glass Modi / Asahi / Saint Gobain 10. Cement Ultratech, Ambuja or equv. 11. Ceramic Tiles HRJ, Bell, Kajaria or equv. 12. Paints ICI, Asian, Nerolac. 13. Keyboard Drawer EBCO 14. Wire Manager / CPU Stand EBCO 15. Vitrified Tiles EURO / RAK 16. Aluminum Sections Jindal 17. Aluminum Cladding Eurobond / Altobond / Alukbond 16 BILL OF QUANTITIES 1. The Bill of Quantities shall be read in conjunction with the Drawings, Conditioners of Contract and Specifications, as these documents are jointly explanatory & descriptive of the works included in the Contract. 2. General directions and descriptions of work and materials given elsewhere in the Contract documents are not necessarily repeated in the Bill of Quantities. Reference is to be made to the other documents for information. 3. The Contractor shall be deemed to have visited the site before preparing his Tender and to have examined for himself the conditions under which the work will be priced and all other factors affecting the execution of the work and the cost thereof. 4. The Quantities of work and m aterial in the Bill of Quantities are not to be considered as limiting or extending the scope of work to be done and materials to be supplied by the Contractor. The quantities in the Bill of Quantities are an estim ate of the amount work but the work will be measured on complete and the contractor will be paid on the actual measurem ent of work approved by the Architect. 5. Any special methods of measurements used are stated at the head of or in text of the Bills of Quantities for the items affected. All other items are measured net in accordance with the drawings and no allowance has been made for wastage. Unless otherwise specified measurements shall be as per relevant Indian Standard. 6. A price or rate in figures is to be entered against the item in the Bill of Quantities, whether quantities stated or not. Item against which no price is tendered will be considered as covered by other prices or rates in the Bills. 7. The prices and rates interested are to be the full inclusive value of the works described under the various items, including all costs and expenses which may be required for the completion of the work described, together with all cost and obligations set forth or im plied in the conditions of Contract, Specifications and the Drawings. 8. Some finishing items may be quantity wise completely altered (either added or omitted) and the same shall not affect any rates quotes. 9. Where prices have been entered against Lum p sum items, payment for such affected items shall be made in proportion to the extent of which works have been done at the time of billing and the same be at discretion of the Architect. 10. “Providing and Fixing” shall mean that the Contractor has to provide such materials not being procured and borne by the Bank, but which are required for the item and if no materials need be provided by the Contractor, the rate shall be only for fixing of the component covered in the item. 17 .
© Copyright 2024